The General Contractor Contract serves as a fundamental legal instrument in Canadian construction projects, establishing the rights, obligations, and responsibilities between property owners and general contractors. This document is essential when engaging a general contractor for any significant construction work, whether commercial, residential, or industrial. It incorporates crucial elements required by Canadian federal and provincial legislation, including compliance with the Construction Act, Occupational Health and Safety regulations, and provincial building codes. The contract addresses key aspects such as payment terms, construction timelines, quality standards, insurance requirements, and dispute resolution mechanisms, while allowing for customization based on project-specific needs and provincial variations in construction law. It's designed to protect both parties' interests while ensuring smooth project execution within the Canadian legal framework.
Your data doesn't train Genie's AI
You keep IP ownership聽of your information
Thank you! Your submission has been received!
Oops! Something went wrong while submitting the form.
OR
Let tiktok成人版's market-leading legal AI identify missing terms, unusual language, compliance issues and more - in just seconds.
1. Parties: Identification and details of the Owner and the General Contractor, including legal names, addresses, and registration numbers
2. Background: Context of the agreement, including project overview and parties' intentions
3. Definitions: Detailed definitions of key terms used throughout the contract
4. Scope of Work: Detailed description of the construction work to be performed, including specifications and deliverables
5. Contract Price and Payment Terms: Total contract value, payment schedule, progress payments, and holdback requirements
6. Project Timeline: Start date, completion date, milestones, and provisions for extensions
7. Contractor's Obligations: Key responsibilities including permits, licenses, workforce, materials, and supervision
8. Owner's Obligations: Responsibilities of the owner including site access, approvals, and owner-supplied materials
9. Changes and Change Orders: Process for requesting, approving, and implementing changes to the scope of work
10. Insurance and Indemnification: Required insurance coverage and indemnification obligations of both parties
11. Health and Safety: Safety requirements, compliance with regulations, and safety reporting procedures
12. Warranties and Deficiencies: Warranty terms, deficiency correction process, and quality standards
13. Termination: Conditions and procedures for contract termination by either party
14. Dispute Resolution: Process for resolving disputes, including mediation and arbitration procedures
15. General Provisions: Standard legal provisions including governing law, notices, and assignment rights
1. Environmental Protection: Specific environmental requirements and procedures, used when project has significant environmental implications
2. Subcontractor Management: Rules and procedures for engaging and managing subcontractors, used when subcontracting is permitted
3. Force Majeure: Provisions for handling unforeseen circumstances and events beyond parties' control
4. Liquidated Damages: Specific damages for delay or non-performance, used when parties agree to predetermined damage amounts
5. Bonding Requirements: Performance and payment bond requirements, used for larger projects or when required by owner
6. Site Security: Special security requirements, used for sensitive or high-security locations
7. Quality Control Program: Detailed quality control procedures, used for complex projects with specific quality requirements
8. Material Storage and Handling: Specific requirements for material management, used when project involves sensitive or valuable materials
1. Schedule A - Scope of Work Details: Detailed specifications, drawings, and technical requirements
2. Schedule B - Price Breakdown: Detailed cost breakdown including labor, materials, and overhead
3. Schedule C - Project Schedule: Detailed timeline with milestones and critical path activities
4. Schedule D - Required Insurance: Specific insurance requirements and coverage limits
5. Schedule E - Key Personnel: List of key project personnel and their responsibilities
6. Schedule F - Equipment and Materials: List of major equipment and materials to be used
7. Schedule G - Safety Procedures: Detailed safety protocols and procedures
8. Schedule H - Forms and Certificates: Required forms including payment applications and completion certificates
9. Appendix 1 - Technical Specifications: Detailed technical specifications and requirements
10. Appendix 2 - Site Plan: Detailed site plans and layouts
Relevant legal definitions
Clauses
Relevant Industries
Commercial Construction
Residential Construction
Industrial Construction
Infrastructure Development
Real Estate Development
Institutional Construction
Healthcare Facilities
Educational Facilities
Retail Construction
Manufacturing Facilities
Hospitality Construction
Government Buildings
Transportation Infrastructure
Relevant Teams
Legal
Construction
Project Management
Procurement
Finance
Operations
Risk Management
Quality Assurance
Health and Safety
Commercial
Development
Contracts Administration
Relevant Roles
Construction Project Manager
Contract Administrator
Legal Counsel
Property Developer
Facility Manager
Construction Manager
Risk Manager
Procurement Manager
Chief Financial Officer
Operations Director
Site Superintendent
Quality Control Manager
Health and Safety Coordinator
Cost Controller
Project Engineer
Commercial Director
Development Manager
Find the exact document you need
Joint Venture Agreement Building (Construction)
Canadian-law governed agreement establishing a joint venture between multiple parties for construction project collaboration, including structure, responsibilities, and risk allocation.
find out more
Owner Builder Contractor Agreement
A Canadian legal agreement between a property owner-builder and contractor establishing terms and conditions for construction projects.
find out more
Agreement For Building Contractor
A Canadian-law governed agreement between property owner and building contractor defining construction project terms, obligations, and deliverables.
find out more
Contractor To Subcontractor Contract
A Canadian legal agreement establishing the terms and conditions between a primary contractor and subcontractor, including work scope, payments, and legal obligations.
find out more
Builder Client Contract
A Canadian jurisdiction contract establishing terms and obligations between builders/contractors and clients for construction projects, compliant with provincial construction laws.
find out more
Land Owner Builder Agreement
A Canadian-law governed agreement between property owners and builders defining construction project terms, obligations, and specifications.
find out more
Contract For House (Construction)
A Canadian-law governed contract establishing terms and conditions between property owner and contractor for residential house construction, including work scope, payments, and compliance requirements.
find out more
Third Party Agreement (Construction)
A Canadian-law governed agreement establishing terms and conditions for third-party construction services, including provincial construction law compliance.
find out more
Project Management Contract In (Construction)
A Canadian-law governed agreement between client and project manager for construction project management services, defining services, responsibilities, and compensation.
find out more
Project Management Agreement (Construction)
A Canadian legal agreement establishing the terms and conditions for professional project management services in construction projects, defining scope, responsibilities, and obligations of the project manager and client.
find out more
Joint Venture Agreement For (Construction)
A Canadian-law governed agreement establishing a joint venture between construction industry partners, defining their collaboration terms and responsibilities.
find out more
Independent Contractor Agreement For (Construction)
Canadian-compliant Independent Contractor Agreement for construction projects, establishing terms for contractor engagement while meeting federal and provincial requirements.
find out more
Contract Between Builder And Homeowner
A Canadian construction agreement between a builder and homeowner outlining project terms, obligations, and compliance with federal and provincial regulations.
find out more
Construction Agreement And Sale Agreement
A Canadian legal agreement combining construction terms and property sale conditions, governing both development and transfer of property.
find out more
Agreement Between Builder And Owner
A Canadian-law governed construction contract between a builder and property owner defining project terms, conditions, and obligations.
find out more
Concrete Contractor Contract
A Canadian-law governed contract between a client and concrete contractor establishing terms for concrete construction services, including scope, specifications, and compliance requirements.
find out more
Contract Between Contractor And Owner
A Canadian legal agreement between a property owner and contractor defining the terms, conditions, and obligations for construction or renovation projects.
find out more
Standard Contractor Contract
A Canadian-law governed agreement establishing the terms and conditions between a company and an independent contractor, ensuring clear relationship definition and mutual protection of interests.
find out more
House Building Contract Agreement
A Canadian-law governed agreement between property owner and contractor for residential house construction, incorporating federal and provincial building requirements.
find out more
Residential Cost Plus Contract
A Canadian residential construction agreement structured on a cost-plus basis, establishing terms for actual costs plus contractor's fee with provincial regulatory compliance.
find out more
Construction Company Partnership Agreement
A Canadian-law governed agreement establishing a partnership between construction industry parties, defining their rights, responsibilities, and operational framework.
find out more
Builder And Land Owner Agreement
A Canadian-law governed agreement between a builder and land owner establishing terms, obligations, and conditions for construction projects.
find out more
Standard General Contractor Agreement
A Canadian-law governed agreement between property owner and general contractor for construction project execution, outlining key terms, conditions, and responsibilities.
find out more
Standard Building Contract
Canadian-law governed building contract establishing terms between owner and contractor for construction projects.
find out more
Construction Equipment Rental Contract
A Canadian law-governed agreement establishing terms and conditions for construction equipment rental, incorporating federal and provincial requirements for equipment operation and safety.
find out more
Contractor Contingency Agreement
Canadian agreement governing performance-based compensation arrangements between companies and independent contractors, with payment contingent on specific achieved outcomes.
find out more
Construction Completion Agreement
A Canadian legal agreement that outlines the terms and conditions for completing outstanding construction work and addressing deficiencies, compliant with provincial construction laws.
find out more
Construction Agreement Between Client And Contractor
A Canadian-law governed agreement between a project owner and contractor establishing terms, conditions, and obligations for construction project execution.
find out more
Builder Purchase Agreement
A Canadian legal agreement between a builder and purchaser for the construction and sale of a new property, outlining construction terms, payments, and warranties.
find out more
Agreement For Construction Of House With Material
A Canadian-law governed agreement for residential house construction, including materials supply, detailing contractor and owner obligations, specifications, and terms.
find out more
Home Improvement Construction Contract
A Canadian-compliant construction contract template for home improvement projects, establishing terms between contractors and homeowners.
find out more
Pre Construction Purchase Agreement
A Canadian legal agreement for purchasing property before construction completion, outlining terms, specifications, and obligations between developer and buyer under provincial regulations.
find out more
New Construction Purchase Agreement
A Canadian legal agreement for the purchase and sale of newly constructed properties, outlining construction specifications, warranties, and closing requirements.
find out more
Construction Finders Fee Agreement
A Canadian-law governed agreement establishing terms for identifying and introducing construction opportunities in exchange for finder's fees.
find out more
Collaboration Agreement For Construction Of Building
A Canadian-law governed agreement establishing collaboration terms between parties involved in building construction, defining roles, responsibilities, and operational procedures.
find out more
Simple Residential Construction Contract
A Canadian residential construction agreement template that governs the relationship between homeowners and contractors for residential building projects.
find out more
Fence Construction Agreement
A Canadian-law governed agreement between property owner and contractor for fence construction services, including terms, specifications, and compliance requirements.
find out more
Construction Disbursement Agreement
A Canadian legal agreement governing the controlled release of construction financing funds, establishing terms and procedures for disbursements during construction phases.
find out more
Landscape Contractor Contract
A Canadian-law governed agreement between a landscape contractor and property owner/manager for landscaping services and maintenance.
find out more
Construction Owner's Representative Contract
A Canadian-law governed agreement establishing the terms and conditions for a construction owner's representative to manage and oversee construction projects on behalf of the property owner.
find out more
骋别苍颈别鈥檚 Security Promise
Genie is the safest place to draft. Here鈥檚 how we prioritise your privacy and security.
Your documents are private:
We do not train on your data; 骋别苍颈别鈥檚 AI improves independently
All data stored on Genie is private to your organisation
Your documents are protected:
Your documents are protected by ultra-secure 256-bit encryption
We are ISO27001 certified, so your data is secure
Organizational security:
You retain IP ownership of your documents and their information
You have full control over your data and who gets to see it
.png)