The House Construction Agreement Between Owner Contractor is a vital legal document used in Canadian residential construction projects when a property owner engages a contractor to build a new house. This agreement is essential for projects governed by Canadian federal and provincial construction laws, including the National Building Code of Canada and provincial variations. It provides a detailed framework covering construction specifications, payment schedules, timelines, quality standards, warranty terms, and dispute resolution procedures. The document is particularly important as it protects both parties' interests while ensuring compliance with local building regulations, construction standards, and consumer protection laws. It should be used at the commencement of any residential construction project and includes crucial elements such as scope of work, material specifications, insurance requirements, and change order procedures.
Your data doesn't train Genie's AI
You keep IP ownership聽of your information
Thank you! Your submission has been received!
Oops! Something went wrong while submitting the form.
OR
Let tiktok成人版's market-leading legal AI identify missing terms, unusual language, compliance issues and more - in just seconds.
1. Parties: Identifies and provides full details of the Owner and Contractor, including legal names, addresses, and contact information
2. Background: Explains the context of the agreement, including the Owner's desire to construct a house and the Contractor's qualifications
3. Definitions: Defines key terms used throughout the agreement to ensure clear interpretation
4. Scope of Work: Detailed description of the construction work to be performed, including general specifications and standards
5. Contract Price and Payment Terms: Specifies the total contract price, payment schedule, and conditions for payment
6. Project Timeline: Sets out the construction schedule, including start date, milestone dates, and completion date
7. Contractor's Obligations: Lists all responsibilities of the contractor, including permits, materials, labor, and supervision
8. Owner's Obligations: Specifies owner's responsibilities, including site access, utilities, and timely decisions
9. Changes and Change Orders: Process for requesting, approving, and implementing changes to the scope of work
10. Insurance and Indemnification: Details required insurance coverage and indemnification obligations
11. Warranties and Defects: Specifies warranty terms, defect correction process, and quality standards
12. Termination: Conditions and process for terminating the agreement by either party
13. Dispute Resolution: Process for resolving disputes, including mediation and arbitration procedures
14. General Provisions: Standard legal provisions including notices, governing law, and entire agreement
1. Environmental Requirements: Special environmental considerations and requirements, used when project has specific environmental impacts
2. Heritage Conservation: Special requirements for construction involving heritage properties or areas
3. Financing Conditions: Terms related to project financing, used when construction depends on specific financing arrangements
4. Site Security: Special security requirements for the construction site, used in high-risk or urban areas
5. Temporary Facilities: Requirements for temporary structures and facilities, used for larger projects
6. Subcontractor Provisions: Specific terms governing subcontractor use and management, used when subcontracting is anticipated
1. Schedule A - Construction Plans and Drawings: Detailed architectural and engineering drawings approved for construction
2. Schedule B - Technical Specifications: Detailed specifications for materials, finishes, and construction methods
3. Schedule C - Payment Schedule: Detailed breakdown of payment milestones and amounts
4. Schedule D - Construction Timeline: Detailed project schedule with milestones and critical path
5. Schedule E - Material Specifications: Detailed list of approved materials and suppliers
6. Schedule F - Warranty Terms: Detailed warranty terms and conditions for different components
7. Appendix 1 - Building Permits: Copies of all required building permits and approvals
8. Appendix 2 - Insurance Certificates: Copies of required insurance certificates
9. Appendix 3 - Contractor's Licenses: Copies of contractor's licenses and certifications
Relevant legal definitions
Clauses
Relevant Industries
Residential Construction
Real Estate Development
Construction Management
Architecture and Design
Building Materials and Supply
Construction Insurance
Property Development
Home Building
Construction Consulting
Property Management
Relevant Teams
Legal
Construction Management
Project Management
Contract Administration
Risk and Compliance
Quality Assurance
Procurement
Operations
Business Development
Client Relations
Relevant Roles
Construction Manager
Project Manager
General Contractor
Contract Administrator
Legal Counsel
Architect
Quantity Surveyor
Site Supervisor
Building Inspector
Property Developer
Construction Estimator
Procurement Manager
Risk Manager
Quality Control Manager
Compliance Officer
Find the exact document you need
Cession Agreement In (Construction)
A Canadian legal agreement facilitating the transfer of rights and obligations for an ongoing construction project from one contractor to another, ensuring compliance with federal and provincial construction laws.
find out more
Agreement With Builder For (Construction)
A Canadian construction agreement between property owner and builder outlining project terms, obligations, and legal requirements.
find out more
Tri Party Agreement (Construction)
A Canadian-law governed agreement establishing rights and obligations between three parties in a construction project, incorporating provincial construction laws and regulations.
find out more
Vesting Agreement (Construction)
A Canadian legal agreement governing the transfer of property rights linked to construction project milestones and completion stages.
find out more
Owner Contractor Construction Agreement
A Canadian construction contract between property owner and contractor, establishing terms for project execution while ensuring compliance with federal and provincial construction laws.
find out more
Joint Check Agreement In (Construction)
A Canadian construction industry agreement establishing a three-party payment arrangement where checks are issued jointly to a subcontractor and their supplier to ensure secure payment for materials or services.
find out more
Project Consortium Agreement
A Canadian-law governed agreement establishing terms and governance structure for multi-party project collaboration, including rights, responsibilities, and risk allocation between consortium members.
find out more
Project Labor Agreement
Canadian-law governed agreement establishing unified labor terms and conditions for major construction projects between owners, contractors, and unions.
find out more
Novation Agreement (Construction)
A Canadian law-governed agreement that substitutes a new contractor for an existing contractor in a construction contract, transferring all rights, obligations, and liabilities.
find out more
Framework Agreement (Construction)
A Canadian-law governed agreement establishing terms and conditions for ongoing construction services between client and contractor, with provisions for multiple project executions.
find out more
Remodeling Agreement
Canadian-law governed agreement between contractor and property owner for renovation works, detailing project scope, terms, and obligations.
find out more
Project Delivery Partner Agreement
A Canadian-law governed agreement establishing a strategic partnership between a client and project delivery partner, defining terms for collaborative project execution.
find out more
Project Labour Agreement
A Canadian-law governed agreement establishing labor terms and conditions for all contractors and unions on a construction project, ensuring unified working standards and compliance with provincial regulations.
find out more
Freelance Project Contract
A Canadian-law governed agreement establishing terms and conditions between a client and freelancer for project-based work.
find out more
Construction Teaming Agreement
A Canadian-law governed agreement establishing collaboration terms between construction industry parties for joint project pursuit and execution.
find out more
Agreement For Construction Of House
A Canadian-law governed agreement establishing terms and conditions for residential house construction, including scope, payments, timelines, and quality standards.
find out more
General Contractor Work Agreement
A Canadian-law governed agreement between an owner and general contractor establishing terms and conditions for construction services.
find out more
Construction Operating Agreement
A Canadian jurisdiction agreement governing construction operations, including safety, standards, and operational procedures in compliance with federal and provincial regulations.
find out more
Project Agreement Between Two Companies
A Canadian-law governed agreement establishing terms and conditions for project collaboration between two companies, including scope, deliverables, and mutual obligations.
find out more
Construction Easement Agreement
A Canadian legal agreement granting temporary property access rights for construction activities, defining terms, conditions, and obligations of all parties involved.
find out more
Residential Construction Agreement
A Canadian-law governed agreement between property owner and contractor for residential construction, detailing project scope, terms, and obligations.
find out more
Project Partnering Agreement
A Canadian-law governed agreement establishing terms and conditions for multi-party project collaboration and partnership arrangements.
find out more
Mining Concession Agreement
A Canadian-law governed agreement granting mining rights and establishing operational terms for mineral resource extraction, subject to federal and provincial regulations.
find out more
Consortium Partnership Agreement
A Canadian law-governed agreement establishing and regulating consortium partnerships between multiple parties, defining collaboration terms, resource sharing, and governance structure.
find out more
Program Management Agreement
A Canadian-law governed agreement establishing terms for professional program management services, including scope, responsibilities, governance, and commercial terms.
find out more
Construction Collaboration Agreement
Canadian-law governed agreement establishing collaborative framework between multiple parties for construction project delivery, including roles, risks, and governance structures.
find out more
Real Estate Development Joint Venture Term Sheet
A Canadian preliminary agreement outlining key terms and conditions for a real estate development joint venture, setting the framework for detailed negotiations and final documentation.
find out more
Letter Of Agreement For Construction Work
A concise, legally binding agreement used in Canadian jurisdictions to outline construction work terms, scope, and responsibilities between contracting parties.
find out more
Business Consortium Agreement
A Canadian-law governed agreement establishing a business consortium, defining member relationships, obligations, and operational framework for collaborative ventures.
find out more
Operation And Maintenance Agreement Solar Power Plant
Canadian-compliant Operation and Maintenance Agreement template for solar power plants, covering maintenance, operations, and regulatory requirements.
find out more
Subcontractor Work Agreement
A Canadian-law governed agreement establishing terms and conditions between a contractor and subcontractor for provision of services or work.
find out more
Project Joint Venture Agreement
A Canadian-law governed agreement establishing a joint venture between parties for a specific project, outlining structure, contributions, and operational framework.
find out more
Building Construction Agreement
Canadian-law governed construction agreement establishing terms and conditions between property owners and contractors for building projects.
find out more
Project Management Agreement
A Canadian-law governed agreement establishing terms for professional project management services, including scope, responsibilities, and compensation structure.
find out more
Project Alliance Agreement
A Canadian-law governed collaborative contract establishing a project alliance structure with shared risks and rewards for complex project delivery.
find out more
Consortium Agreement Construction Project
A Canadian-law governed agreement establishing a consortium between multiple parties for executing a construction project, defining their rights, responsibilities, and operational framework.
find out more
Building Work Agreement
A Canadian-law governed contract between property owner and contractor establishing terms for construction work, including scope, payment, and compliance requirements.
find out more
Renovation Agreement Between Owner And Contractor
A Canadian-law governed agreement between property owner and contractor outlining terms, conditions, and responsibilities for renovation work.
find out more
Project Profit Sharing Agreement
A Canadian-law governed agreement establishing terms for profit sharing between multiple parties in a specific project, including calculation methods and distribution mechanisms.
find out more
Project Implementation Agreement
A Canadian-law governed agreement defining the framework for project implementation, including roles, responsibilities, and delivery requirements.
find out more
骋别苍颈别鈥檚 Security Promise
Genie is the safest place to draft. Here鈥檚 how we prioritise your privacy and security.
Your documents are private:
We do not train on your data; 骋别苍颈别鈥檚 AI improves independently
All data stored on Genie is private to your organisation
Your documents are protected:
Your documents are protected by ultra-secure 256-bit encryption
We are ISO27001 certified, so your data is secure
Organizational security:
You retain IP ownership of your documents and their information
You have full control over your data and who gets to see it
.png)