The Residential Contractor Contract is a specialized agreement designed for use in Denmark when engaging contractors for residential construction, renovation, or improvement projects. This document is essential when a professional contractor undertakes work on private residential properties, ensuring compliance with Danish construction laws, consumer protection regulations, and the AB-Forbruger framework. The contract provides comprehensive coverage of all aspects of the construction project, including detailed specifications, payment terms, timelines, and quality standards. It incorporates specific consumer protections required under Danish law, such as mandatory warranties and dispute resolution procedures. The document is particularly important as it balances the professional contractor's interests with strong consumer protection measures typical of Danish legislation, making it suitable for projects ranging from minor renovations to major residential construction works.
Create a bespoke document in minutes, or upload and review your own.
Thank you! Your submission has been received!
Oops! Something went wrong while submitting the form.
Get your first 2 documents free
Your data doesn't train Genie's AI
You keep IP ownership聽of your information
Key Requirements PROMPT example:
Residential Contractor Contract
I need a Residential Contractor Contract for a complete house renovation project in Copenhagen, starting March 2025, with specific provisions for sustainable materials and staged payments linked to completion milestones.
1. Parties: Identification of the contractor and the residential client, including full legal names, addresses, and registration numbers
2. Background: Brief context of the construction project and the parties' intention to enter into this agreement
3. Definitions: Key terms used throughout the agreement defined for clarity and consistency
4. Scope of Work: Detailed description of the construction work to be performed, including specific inclusions and exclusions
5. Project Timeline: Start date, completion date, and key milestones for the construction project
6. Contract Price and Payment Terms: Total price, payment schedule, and conditions for payments including any retention amounts
7. Materials and Quality: Specifications for materials to be used and quality standards to be met
8. Contractor's Obligations: Key responsibilities of the contractor including warranties, insurance, and compliance requirements
9. Client's Obligations: Responsibilities of the client including access, utilities, and required permissions
10. Changes and Variations: Process for requesting and implementing changes to the scope of work
11. Warranties and Defects: Warranty periods, defects liability, and process for addressing defects
12. Insurance and Liability: Required insurance coverage and allocation of risks between parties
13. Termination: Circumstances under which either party may terminate the contract and consequences
14. Dispute Resolution: Process for resolving disputes, including reference to the Danish Building and Construction Arbitration Board
15. Governing Law: Confirmation of Danish law as governing law and jurisdiction
1. Subcontractors: Terms regarding the use and management of subcontractors - include when subcontractors will be used
2. Special Permits and Approvals: Details of required permits and who is responsible - include when special permits are needed
3. Environmental Requirements: Specific environmental obligations and compliance requirements - include for projects with significant environmental impact
4. Site Safety and Access: Detailed safety protocols and site access requirements - include for complex or long-duration projects
5. Storage and Security: Requirements for materials storage and site security - include when significant materials will be stored on site
6. Utilities During Construction: Arrangements for utilities during the construction period - include when significant utility usage is expected
7. Temporary Works: Requirements for temporary structures or facilities - include when temporary works are needed
8. Force Majeure: Provisions for unforeseen circumstances - include for longer-term projects
1. Schedule A - Detailed Scope of Works: Comprehensive technical specifications and detailed description of all works to be performed
2. Schedule B - Project Timeline: Detailed project schedule including all milestones and completion dates
3. Schedule C - Payment Schedule: Detailed breakdown of payments, including amounts and triggering events
4. Schedule D - Materials Specifications: Detailed list of all materials to be used, including brands, qualities, and quantities
5. Schedule E - Drawings and Plans: All relevant architectural and construction drawings
6. Schedule F - Insurance Certificates: Copies of required insurance policies and certificates
7. Schedule G - Permits and Approvals: Copies of all relevant permits and approvals
8. Schedule H - Quality Control Plan: Detailed quality control procedures and checkpoints
Authors
Relevant legal definitions
Clauses
Relevant Industries
Construction
Real Estate
Home Improvement
Residential Development
Building Materials
Architecture
Interior Design
Property Management
Relevant Teams
Legal
Operations
Construction
Project Management
Procurement
Quality Assurance
Client Relations
Risk Management
Compliance
Contract Administration
Relevant Roles
Construction Manager
Project Manager
Contract Administrator
Legal Counsel
Quantity Surveyor
Site Supervisor
Procurement Manager
Risk Manager
Quality Control Manager
Client Relations Manager
Building Inspector
Architect
Construction Estimator
Operations Director
Compliance Officer
Find the exact document you need
Contractor Homeowner Agreement
Danish law-governed agreement between contractor and homeowner for residential construction or renovation work.
find out more
Construction Cost Plus Contract
Danish law-governed construction agreement establishing a cost-plus pricing structure between owner and contractor, with reimbursement for approved costs plus agreed fee.
find out more
Standard Contractor Contract
A Danish law-governed contract template establishing terms and conditions between a company and independent contractor.
find out more
Agreement For Construction Work
Danish law construction agreement defining the terms and conditions between client and contractor for building works, aligned with AB 18 requirements.
find out more
Residential Contractor Contract
Danish law-compliant contract between a contractor and residential client for home construction or renovation works, incorporating consumer protection and construction regulations.
find out more
Building Work Agreement
A Danish law-governed agreement between a building contractor and property owner that establishes terms and conditions for construction works, incorporating Danish construction regulations and industry standards.
find out more
Construction Subcontract
Danish law-governed agreement between main contractor and subcontractor for construction works, aligned with AB 18 standards.
find out more
General Contractor Agreement With Owner
Danish law construction agreement between owner and general contractor, incorporating AB 18 standards and defining project execution terms.
find out more
Contract Agreement For Construction Work
Danish law-governed construction agreement establishing terms between employer and contractor, following AB 18 framework and Danish Construction Act requirements.
find out more
Simple Construction Contract
Danish law construction contract template establishing key terms between employer and contractor, aligned with Danish Construction Act and AB 18 principles.
find out more
Standard Construction Contract
Danish law construction contract based on AB 18 framework, governing the relationship between employer and contractor for building works.
find out more
Download our whitepaper on the future of AI in Legal
By providing your email address you are consenting to our Privacy Notice.
骋别苍颈别鈥檚 Security Promise
Genie is the safest place to draft. Here鈥檚 how we prioritise your privacy and security.
Your documents are private:
We do not train on your data; 骋别苍颈别鈥檚 AI improves independently
All data stored on Genie is private to your organisation
Your documents are protected:
Your documents are protected by ultra-secure 256-bit encryption
Our bank-grade security infrastructure undergoes regular external audits
We are ISO27001 certified, so your data is secure
Organizational security
You retain IP ownership of your documents
You have full control over your data and who gets to see it
Innovation in privacy:
Genie partnered with the Computational Privacy Department at Imperial College London
Together, we ran a 拢1 million research project on privacy and anonymity in legal contracts
Want to know more?
Visit our for more details and real-time security updates.
Read our Privacy Policy.