The Turnkey Project Agreement is a sophisticated contractual instrument used when an employer requires a complete, ready-to-use facility or infrastructure delivered by a single contractor. This agreement, governed by Danish law and incorporating relevant EU regulations, is particularly suitable for complex projects where the employer wants to minimize project interface risks by allocating comprehensive responsibility to one contractor. The document encompasses all aspects of project delivery, from initial design through construction to final commissioning and handover, including detailed technical specifications, performance guarantees, and warranty obligations. It incorporates key requirements from Danish construction law, including AB 18 principles, while addressing specific needs for quality assurance, testing procedures, and completion criteria. The agreement is structured to provide clear allocation of risks and responsibilities, comprehensive project scope definition, and detailed procedures for project execution and dispute resolution.
Create a bespoke document in minutes, or upload and review your own.
Thank you! Your submission has been received!
Oops! Something went wrong while submitting the form.
Get your first 2 documents free
Your data doesn't train Genie's AI
You keep IP ownership聽of your information
Key Requirements PROMPT example:
Turnkey Project Agreement
I need a Turnkey Project Agreement for a 50MW solar power plant in Denmark, with performance guarantees for minimum energy output and completion scheduled for October 2025; the agreement should include specific provisions for environmental compliance and grid connection requirements.
1. Parties: Identification of the employer and contractor, including their legal details and representatives
2. Background: Context of the project and purpose of the agreement
3. Definitions and Interpretation: Definitions of key terms and rules for interpreting the agreement
4. Scope of Works: Detailed description of the works to be performed, including design, construction, and commissioning responsibilities
5. Contract Price and Payment Terms: Fixed price, payment schedule, variations, and payment conditions
6. Time for Completion: Project schedule, milestones, and completion dates
7. Contractor's Obligations: General and specific obligations including design, procurement, construction, testing, and commissioning
8. Employer's Obligations: Access to site, permits, approvals, and other employer responsibilities
9. Design Responsibility: Contractor's design obligations, fitness for purpose, and compliance with specifications
10. Quality Assurance and Control: Quality standards, inspection procedures, and testing requirements
11. Testing and Commissioning: Procedures for testing, commissioning, and performance verification
12. Completion and Handover: Requirements for substantial completion, punch list items, and final acceptance
13. Defects Liability: Warranty period, remedial works, and defect correction procedures
14. Changes and Variations: Procedures for handling changes to scope, price, or schedule
15. Risk and Insurance: Risk allocation, required insurance coverage, and liability provisions
16. Force Majeure: Definition of force majeure events and consequences
17. Suspension and Termination: Rights and procedures for suspension and termination
18. Dispute Resolution: Procedures for resolving disputes, including mediation and arbitration
19. Governing Law: Confirmation of Danish law as governing law and jurisdiction
20. General Provisions: Miscellaneous legal provisions including notices, assignments, and amendments
1. Financing Arrangements: Include when project involves specific financing requirements or lender conditions
2. Technology License: Include when proprietary technology or licenses are part of the scope
3. Environmental Compliance: Include when project has significant environmental impacts or requirements
4. Local Content Requirements: Include when project must meet specific local content obligations
5. Interface Management: Include when multiple contractors or interfaces need coordination
6. Export Control Compliance: Include when project involves international procurement or technology transfer
7. Step-In Rights: Include when lenders or employer require step-in rights provisions
8. Performance Bonds: Include when specific performance security arrangements are required
1. Technical Specifications: Detailed technical requirements and performance specifications
2. Scope of Work: Detailed description of works including drawings and technical documents
3. Project Schedule: Detailed timeline, milestones, and critical path activities
4. Price Schedule: Breakdown of contract price, payment milestones, and rates
5. Site Information: Site data, conditions, and access requirements
6. Forms of Certificates: Templates for completion, acceptance, and other certificates
7. Performance Guarantees: Specific performance parameters and testing procedures
8. List of Approved Subcontractors: Pre-approved subcontractors and suppliers
9. Forms of Bonds and Guarantees: Templates for required bonds and guarantees
10. Insurance Requirements: Detailed insurance coverage requirements
11. Health, Safety and Environment Requirements: HSE standards and procedures
12. Quality Assurance Plan: Detailed quality management procedures and requirements
13. Spare Parts List: Required spare parts and maintenance materials
14. Operating and Maintenance Manuals: Requirements for O&M documentation
Authors
Relevant legal definitions
Clauses
Relevant Industries
Energy and Utilities
Industrial Manufacturing
Infrastructure Development
Commercial Real Estate
Healthcare Facilities
Data Centers
Renewable Energy
Transportation
Waste Management
Pharmaceutical Manufacturing
Chemical Processing
Food and Beverage Production
Relevant Teams
Legal
Commercial
Project Management
Engineering
Procurement
Construction
Finance
Risk Management
Quality Assurance
Health Safety and Environment
Operations
Business Development
Technical Services
Contract Administration
Relevant Roles
Project Director
Contract Manager
Commercial Manager
Legal Counsel
Project Manager
Construction Manager
Design Manager
Procurement Manager
Chief Financial Officer
Risk Manager
Technical Director
Quality Assurance Manager
HSE Manager
Operations Director
Engineering Manager
Cost Controller
Claims Manager
Business Development Director
Find the exact document you need
Construction Business Partnership Agreement
Danish law-governed agreement establishing a partnership between construction industry entities, defining terms, obligations, and operational framework.
find out more
Agreement With Builder For (Construction)
Danish law-governed construction agreement between building owner and contractor, establishing terms for construction project execution and compliance with Danish building regulations.
find out more
Vesting Agreement (Construction)
A legal agreement governing progressive ownership transfer during construction projects under Danish law.
find out more
Build Agreement
Danish law construction contract establishing terms and conditions between employer and contractor under AB 18 framework.
find out more
Novation Agreement (Construction)
A Danish law agreement transferring rights and obligations under a construction contract from an original contractor/consultant to a new one, ensuring project continuity under Danish construction regulations.
find out more
Turnkey Project Agreement
Danish law-governed agreement for complete turnkey project delivery, covering design through commissioning with contractor's full responsibility for operational facility delivery.
find out more
Residential Contractor Agreement
A Danish law-governed agreement between a contractor and homeowner for residential construction or renovation works, incorporating Danish construction and consumer protection requirements.
find out more
Mural Agreement
Danish law-governed agreement for commissioning and installing mural artwork, defining rights and responsibilities between artists and property owners.
find out more
Project Hire Contract
Danish law-governed agreement for project-based employment, defining project scope, deliverables, and employment terms.
find out more
Pipeline Agreement
Danish law-governed agreement for pipeline construction, operation, and maintenance, incorporating local regulatory requirements and EU compliance measures.
find out more
Consortium Partnership Agreement
Danish law-governed agreement establishing and regulating a consortium partnership between multiple organizations, defining collaboration terms and governance structure.
find out more
Building Construction Agreement
Danish law-governed construction agreement establishing terms between building owner and contractor, incorporating AB 18 principles and local building regulations.
find out more
Project Alliance Agreement
A Danish law-governed collaborative agreement establishing a project alliance framework for joint project delivery with shared risks and rewards.
find out more
Project Delivery Agreement
Danish law-governed agreement establishing terms and conditions for project delivery, including scope, deliverables, and party obligations.
find out more
Pilot Project Agreement
Danish law agreement for establishing and governing pilot projects, including scope, responsibilities, and IP rights.
find out more
Minor Works Agreement
A Danish law-governed construction contract for small-scale building projects and renovations, incorporating key principles from Danish construction law and the AB-System.
find out more
Turnkey Contract Agreement
A Danish law-governed agreement for turnkey construction projects, establishing comprehensive terms for design-build project delivery under ABT 18 principles.
find out more
Commercial Supply Agreement
A Danish law-governed agreement establishing terms and conditions for regular commercial supply of goods between supplier and buyer.
find out more
Engineering Procurement And Construction Agreement
Danish law-governed agreement for comprehensive engineering, procurement, and construction projects, detailing contractor obligations and project execution requirements.
find out more
Project Cooperation Agreement
Danish law-governed agreement establishing terms and conditions for multi-party project collaboration, including responsibilities, resources, and rights.
find out more
Project Agreement Contract
Danish law-governed agreement establishing terms and conditions for project execution, including scope, deliverables, timelines, and responsibilities.
find out more
New Construction Agreement
Danish law-governed agreement for new construction projects, incorporating AB 18 requirements and establishing key terms between client and contractor.
find out more
Renovation Agreement
Danish law-governed agreement outlining terms and conditions for property renovation work, including scope, pricing, timeline, and responsibilities.
find out more
Demolition Agreement
Danish law-governed agreement setting terms and conditions for demolition works, including safety, environmental, and regulatory requirements.
find out more
Project Development Agreement
A Danish law-governed agreement between developer and client establishing terms and conditions for property or infrastructure development projects.
find out more
Proof Of Concept Agreement
A Danish law agreement governing the testing and evaluation of new technologies or solutions, establishing terms for proof of concept implementation.
find out more
Pre Construction Agreement
Danish law-governed agreement establishing terms and conditions for pre-construction services between client and contractor.
find out more
Download our whitepaper on the future of AI in Legal
By providing your email address you are consenting to our Privacy Notice.
骋别苍颈别鈥檚 Security Promise
Genie is the safest place to draft. Here鈥檚 how we prioritise your privacy and security.
Your documents are private:
We do not train on your data; 骋别苍颈别鈥檚 AI improves independently
All data stored on Genie is private to your organisation
Your documents are protected:
Your documents are protected by ultra-secure 256-bit encryption
Our bank-grade security infrastructure undergoes regular external audits
We are ISO27001 certified, so your data is secure
Organizational security
You retain IP ownership of your documents
You have full control over your data and who gets to see it
Innovation in privacy:
Genie partnered with the Computational Privacy Department at Imperial College London
Together, we ran a 拢1 million research project on privacy and anonymity in legal contracts
Want to know more?
Visit our for more details and real-time security updates.
Read our Privacy Policy.