The Simple Construction Agreement is designed for use in England and Wales when parties need a clear, uncomplicated contractual framework for construction projects. This document is particularly valuable for projects where standard industry forms like JCT or NEC contracts would be overly complex or costly. The agreement incorporates key requirements from the Housing Grants, Construction and Regeneration Act 1996 and other relevant legislation, while maintaining accessibility and ease of use. It typically includes essential provisions for scope, payment, timing, and quality standards, making it suitable for straightforward construction works where the risks and complexities are relatively low.
Your data doesn't train Genie's AI
You keep IP ownership聽of your information
Thank you! Your submission has been received!
Oops! Something went wrong while submitting the form.
OR
Let tiktok成人版's market-leading legal AI identify missing terms, unusual language, compliance issues and more - in just seconds.
1. Parties: Details of the contractor and employer
2. Background: Context of the agreement and basic information about the project
3. Definitions: Key terms used throughout the agreement
4. Scope of Works: Detailed description of the construction work to be performed
5. Contract Price: Amount to be paid and payment terms
6. Programme: Timeline and completion dates
7. Contractor Obligations: Main responsibilities of the contractor
8. Employer Obligations: Main responsibilities of the employer
9. Variations: Process for handling changes to the work
10. Termination: Circumstances and process for ending the agreement
1. Insurance: Insurance requirements - for larger projects or when specific risks need to be covered
2. Bonds and Warranties: Performance bonds and warranties - for higher-value projects or when required by third parties
3. Liquidated Damages: Pre-agreed damages for delay - when specific completion dates are crucial
4. Dispute Resolution: Specific dispute resolution procedures - for more complex projects or when standard adjudication isn't sufficient
1. Schedule 1: Specification: Detailed technical specifications of the work
2. Schedule 2: Drawings: Technical drawings and plans
3. Schedule 3: Programme: Detailed timeline of works
4. Schedule 4: Price and Payment Schedule: Breakdown of costs and payment milestones
5. Schedule 5: Site Information: Details about the construction site and access
Relevant legal definitions
Clauses
Relevant Industries
Relevant Teams
Relevant Roles
Find the exact document you need
Simple Project Management Agreement
An England & Wales agreement outlining project management services, including scope, deliverables, timelines, and payment terms.
find out more
Resource Agreement In Project Management
An England & Wales legal document outlining resource allocation and management for project-based work.
find out more
Residential Architect Contract
An England & Wales legal document outlining architect-client obligations in residential construction projects.
find out more
Project Hire Contract
An England & Wales contract outlining terms for project-based external contractor engagements.
find out more
Project Based Employment Agreement
An England & Wales agreement outlining terms for project-specific employment, ensuring legal compliance and mutual protection.
find out more
Project Based Agreement
An England & Wales contract outlining project deliverables, timelines, and intellectual property protections.
find out more
Pipeline Agreement
An England & Wales legal document outlining rights and duties for pipeline infrastructure projects.
find out more
House Building Contractor Agreement
An England & Wales contract outlining terms for residential construction projects, ensuring compliance with construction regulations.
find out more
Freelance Project Contract
An England & Wales contract outlining cleaning service terms, compliance, and responsibilities for commercial or residential properties.
find out more
Construction Teaming Agreement
An England & Wales legal document extending a commercial lease agreement, detailing terms and compliance with property legislation.
find out more
Construction Agreement For Individual House
An England & Wales contract outlining terms for self-employed cleaning services, ensuring compliance and protecting both parties.
find out more
Construction Agreement Between Client And Contractor
A legal contract outlining terms and responsibilities for construction services between a client and contractor.
find out more
Agreement For Construction Of House With Material
An England & Wales contract outlining business consulting terms, responsibilities, and compliance with IR35 regulations.
find out more
Operating Agreement Real Estate Development
A legal framework under English and Welsh law governing the operation and management of real estate development projects between multiple stakeholders.
find out more
Simple Website Development Agreement
An English law agreement governing the relationship between a website developer and client for the creation of a website.
find out more
Simple Residential Construction Contract
An English law contract for residential construction work, establishing terms between property owner and contractor.
find out more
Fence Construction Agreement
A legally binding agreement under English and Welsh law that sets out terms and conditions for fence construction between a contractor and property owner.
find out more
Construction Disbursement Agreement
A legal agreement under English and Welsh law governing the release and management of construction project funds between funders and developers.
find out more
Construction Easement Agreement
A legal agreement under English and Welsh law granting temporary access rights to property for construction purposes.
find out more
Project Partnering Agreement
A collaborative agreement under English and Welsh law establishing partnership terms for complex project delivery.
find out more
Letter Of Intent For Real Estate Development
A preliminary document under English and Welsh law outlining proposed terms for a real estate development project, serving as a framework for negotiations.
find out more
Real Estate Development Term Sheet
A preliminary document outlining key terms for property development projects under English and Welsh law.
find out more
Swimming Pool Construction Agreement
A contract governed by English and Welsh law that sets out terms for swimming pool construction, including specifications, timeline, and responsibilities.
find out more
Standard Construction Agreement
A legally binding construction contract under English and Welsh law that establishes terms between employer and contractor for building works.
find out more
Program Management Agreement
An English law agreement governing the provision of program management services, including terms, responsibilities, and governance structures.
find out more
Engineering And Construction Subcontract
A legally binding agreement under English and Welsh law between a main contractor and subcontractor for specific engineering or construction works.
find out more
Residential Subcontractor Agreement
An English law agreement between a main contractor and subcontractor for residential construction services.
find out more
Project Specific Agreement
A legally binding agreement under English and Welsh law that defines the terms and conditions for executing a specific project.
find out more
Real Estate Development Partnership Agreement
An England and Wales law agreement establishing a partnership structure for real estate development projects, defining partner rights, obligations, and project execution framework.
find out more
Letter Of Agreement For Construction Work
A legally binding agreement under English and Welsh law that establishes terms and conditions between parties for construction works.
find out more
Construction Work Agreement
A legally binding agreement under English and Welsh law that governs the relationship between a contractor and employer for construction works.
find out more
Business Consortium Agreement
A legal agreement under English and Welsh law governing the collaboration between multiple organizations in a business consortium.
find out more
Construction Labor Agreement
A legally binding agreement governing construction employment terms under English and Welsh law.
find out more
Subcontractor Work Agreement
An England and Wales law agreement defining terms between a main contractor and subcontractor for specified construction works.
find out more
Simple Construction Agreement
A straightforward construction contract under English and Welsh law, suitable for smaller-scale building projects.
find out more
Project Employment Contract
An England and Wales law-governed employment contract for fixed-term, project-based work arrangements.
find out more
Construction Subcontracts
An English law agreement between main contractor and subcontractor for specific construction works, governed by England and Wales jurisdiction.
find out more
Project Support Agreement
A legally binding agreement under English and Welsh law that governs the provision of project support services between parties.
find out more
Project Alliance Agreement
A collaborative contract under English and Welsh law that establishes a framework for multiple parties to jointly deliver complex projects while sharing risks and rewards.
find out more
Consortium Agreement Construction Project
A legal agreement under English and Welsh law establishing terms for multiple parties collaborating on a construction project.
find out more
骋别苍颈别鈥檚 Security Promise
Genie is the safest place to draft. Here鈥檚 how we prioritise your privacy and security.
Your documents are private:
We do not train on your data; 骋别苍颈别鈥檚 AI improves independently
All data stored on Genie is private to your organisation
Your documents are protected:
Your documents are protected by ultra-secure 256-bit encryption
We are ISO27001 certified, so your data is secure
Organizational security:
You retain IP ownership of your documents and their information
You have full control over your data and who gets to see it
.png)