The Builder Agreement is a fundamental contract used in the Indian construction industry to formalize the relationship between builders/developers and property owners. This document is essential when engaging a builder for new construction, renovation, or development projects. It comprehensively covers construction specifications, timelines, payment schedules, quality standards, and compliance requirements with Indian construction laws and regulations. The agreement ensures protection for both parties by clearly defining roles, responsibilities, and remedies for breach. It's particularly important in the context of Indian real estate laws, including RERA compliance, and includes provisions for necessary governmental approvals, environmental clearances, and local building regulations. The Builder Agreement serves as both a legal safeguard and a project management tool, helping prevent disputes and ensuring smooth project execution.
Your data doesn't train Genie's AI
You keep IP ownership聽of your information
Thank you! Your submission has been received!
Oops! Something went wrong while submitting the form.
OR
Let tiktok成人版's market-leading legal AI identify missing terms, unusual language, compliance issues and more - in just seconds.
1. Parties: Identification and details of the Builder/Developer and the Owner/Client
2. Background: Context of the agreement, including property details and purpose of construction
3. Definitions: Definitions of key terms used throughout the agreement
4. Scope of Work: Detailed description of construction work to be undertaken, including specifications and standards
5. Project Timeline: Construction schedule, milestones, and completion dates
6. Payment Terms: Payment schedule, amounts, and methods of payment
7. Builder's Obligations: Responsibilities of the builder including quality standards, materials, and workmanship
8. Owner's Obligations: Responsibilities of the owner including site access, approvals, and cooperation
9. Quality and Standards: Construction quality requirements, applicable standards, and inspection procedures
10. Variations and Changes: Process for handling changes to scope, specifications, or design
11. Warranties and Defects: Builder's warranties, defect liability period, and remedy procedures
12. Permits and Approvals: Responsibility for obtaining necessary permits, licenses, and regulatory approvals
13. Insurance and Indemnity: Insurance requirements and indemnification obligations
14. Termination: Grounds and procedure for contract termination
15. Dispute Resolution: Process for resolving disputes including mediation and arbitration
16. Force Majeure: Provisions for handling unforeseen circumstances and delays
17. Governing Law: Applicable law and jurisdiction
18. Notices: Process and addresses for formal communications between parties
1. Environmental Compliance: Specific environmental obligations and compliance requirements, included for projects with significant environmental impact
2. Safety Measures: Detailed safety protocols and requirements, particularly important for large construction projects
3. Subcontracting: Terms governing the appointment and management of subcontractors, included when subcontracting is permitted
4. Intellectual Property: Protection of designs, drawings, and other IP rights, included for projects involving unique designs
5. Confidentiality: Non-disclosure obligations, included when sensitive information is involved
6. Labor Compliance: Specific labor law compliance requirements, included for large projects with significant workforce
7. Liquidated Damages: Pre-determined damages for specific breaches, included when parties agree on fixed compensation for delays
8. Performance Security: Requirements for performance bonds or guarantees, included for high-value projects
9. Site Security: Specific security requirements for the construction site, included for projects in sensitive areas
10. Handover Procedure: Detailed process for project handover, included for complex projects
1. Schedule A - Property Details: Detailed description of the property including location, boundaries, and title details
2. Schedule B - Construction Specifications: Detailed technical specifications, materials, and quality standards
3. Schedule C - Floor Plans and Drawings: Architectural drawings, layouts, and design specifications
4. Schedule D - Payment Schedule: Detailed breakdown of payment stages and amounts
5. Schedule E - Construction Timeline: Detailed project schedule with milestones and completion dates
6. Schedule F - List of Approved Materials: Specifications of approved construction materials and brands
7. Schedule G - Quality Control Requirements: Detailed quality control procedures and acceptance criteria
8. Schedule H - Permits and Approvals: List of required regulatory approvals and their status
9. Appendix 1 - Insurance Requirements: Detailed insurance coverage requirements and terms
10. Appendix 2 - Safety Standards: Detailed safety protocols and requirements
Authors
Relevant legal definitions
Clauses
Relevant Industries
Real Estate
Construction
Infrastructure Development
Commercial Property
Residential Property
Industrial Construction
Urban Development
Hospitality
Retail
Healthcare
Relevant Teams
Legal
Construction
Project Management
Real Estate
Compliance
Procurement
Risk Management
Operations
Finance
Property Development
Relevant Roles
Construction Manager
Project Manager
Real Estate Developer
Legal Counsel
Contract Manager
Property Developer
Site Engineer
Architect
Quantity Surveyor
Compliance Officer
Real Estate Manager
Development Director
Construction Director
Property Manager
Risk Manager
Procurement Manager
Find the exact document you need
Lien Contract
An Indian law-governed agreement establishing a lien right over specified property as security for an underlying obligation.
find out more
Labour Contract Form
A standardized employment agreement compliant with Indian labor laws, establishing terms and conditions of employment between employer and employee.
find out more
House Wiring Contract
An Indian law-governed contract for electrical wiring installation services, specifying technical requirements, safety standards, and compliance with Indian electrical regulations.
find out more
Handyman Maintenance Contract
An Indian law-governed agreement between a handyman/maintenance service provider and property owner/manager, outlining maintenance services, terms, and obligations.
find out more
General Contract
A versatile contract template under Indian law that establishes formal business relationships between parties, compliant with the Indian Contract Act and related legislation.
find out more
Contractor Non Compete Agreement
An Indian law-compliant agreement restricting a contractor's competitive activities during their engagement period, protecting company interests while maintaining enforceability under Section 27 of the Indian Contract Act.
find out more
Contractor Lien Release
An Indian legal document where a contractor waives their right to place a lien on a property after receiving payment for work performed or materials supplied.
find out more
Contract With Builder
An Indian law-governed agreement between property owner and builder for construction works, compliant with RERA and construction regulations.
find out more
Contractors Agreement Form
An Indian law-governed agreement establishing terms and conditions between a hiring entity and a contractor, defining their professional relationship and mutual obligations.
find out more
Conditions Of Contract For (Construction)
Standard construction contract conditions template under Indian law governing rights, obligations, and procedures for construction projects in India.
find out more
Construction Agreement Contract
An Indian law-governed agreement between property owner/developer and contractor establishing terms for construction works, including scope, payments, and compliance requirements.
find out more
Basic Independent Contractor Agreement
An Indian law-governed agreement establishing the terms and conditions between a company and an independent contractor, defining service scope, payment terms, and contractor status.
find out more
Architect Contract Agreement
An Indian law-governed agreement between an architect/architectural firm and client, defining architectural services, fees, and mutual obligations.
find out more
Simple Contract Labor Agreement
An Indian law-compliant agreement between a Principal Employer and Contractor for the provision and management of contract labor services.
find out more
Private Security Contract
An Indian law-governed agreement for private security services provision, compliant with PSARA 2005 and related regulations.
find out more
Payment Contract Agreement
An Indian law-governed agreement establishing payment terms, schedules, and obligations between parties, ensuring compliant and secure monetary transactions.
find out more
Contractor Work Contract
An India-compliant Contractor Work Contract establishing terms and conditions for independent contractor services, including scope, payment, and deliverables.
find out more
Building Construction Labour Contract Agreement
An Indian jurisdiction labor contract agreement for construction projects, establishing terms between principal employers and labor contractors while ensuring compliance with local construction and labor laws.
find out more
Developer Contractor Agreement
An Indian law-governed agreement establishing terms for engaging an independent developer contractor, including service scope, payments, and IP rights.
find out more
Standard Form Of Agreement Between Owner And Contractor
An Indian law-governed agreement between property owner and contractor defining construction project terms, obligations, and deliverables.
find out more
Turnkey Contract
An Indian law-governed contract for the complete design, construction, and delivery of a fully operational facility, where the contractor assumes total responsibility from design through commissioning.
find out more
Time And Materials Contract
An Indian law-governed agreement for charging based on actual time spent and materials used in project delivery, including rates, tracking, and approval processes.
find out more
Standard Renovation Contract
An Indian law-governed contract establishing terms and conditions for property renovation works between owners and contractors.
find out more
Swimming Pool Contract
An Indian law-governed contract for swimming pool construction and installation, detailing specifications, responsibilities, and compliance requirements.
find out more
Suppliers Contract Agreement
An Indian law-governed agreement establishing terms and conditions between a purchaser and supplier for the provision of goods or services.
find out more
Service Contract Proposal
An Indian law-compliant Service Contract Proposal template outlining service arrangements, terms, and obligations between parties under Indian jurisdiction.
find out more
Residential Solar Installation Contract
An Indian law-governed contract for residential solar power system installation, covering technical specifications, warranties, and regulatory compliance.
find out more
Restoration Contract
An Indian law-governed contract specifying terms and conditions for property restoration work, including scope, specifications, timelines, and compliance requirements.
find out more
Receipt Contract
A legally binding document under Indian law that provides formal evidence of a financial transaction or transfer of goods/services, compliant with Indian Contract Act and GST regulations.
find out more
Real Estate Contractor Agreement
An Indian law-governed agreement between property owner/developer and contractor establishing terms and conditions for construction services, including scope, payments, and compliance requirements.
find out more
Proposal And Contract
An Indian law-governed document combining a business proposal with binding contractual terms, establishing commercial and legal parameters for business relationships.
find out more
Owner's Representative Contract
An Indian law-governed agreement appointing a representative to act on behalf of a property owner, defining their authority, responsibilities, and compensation.
find out more
Masonry Contract
An Indian law-governed contract establishing terms and conditions for masonry construction work, including quality standards, specifications, and compliance requirements.
find out more
Marketing Agreement Contract
An Indian law-governed agreement establishing terms between a marketing service provider and client for marketing services delivery, including scope, payments, and compliance requirements.
find out more
Lump Sum Contract
An Indian law-governed fixed-price contract establishing terms for project delivery at a predetermined lump sum amount, with defined scope and milestone-based payments.
find out more
Insurance Agency Agreement
An Indian law-governed agreement establishing the relationship between an insurance company and its agent, compliant with IRDAI regulations.
find out more
Labour Only Subcontractor Agreement
Indian law-compliant agreement template for engaging labor-only subcontractors, ensuring compliance with local labor regulations and statutory requirements.
find out more
Kitchen Renovation Contract
An Indian law-governed contract for kitchen renovation projects, defining scope, terms, and obligations between contractors and property owners.
find out more
Kitchen Contract
An Indian law-governed agreement for kitchen construction or renovation services, outlining project specifications, terms, and obligations of all parties involved.
find out more
Labour Supply Contract
An Indian law-governed agreement between a labor contractor and principal employer for the supply and management of contract workers.
find out more
骋别苍颈别鈥檚 Security Promise
Genie is the safest place to draft. Here鈥檚 how we prioritise your privacy and security.
Your documents are private:
We do not train on your data; 骋别苍颈别鈥檚 AI improves independently
All data stored on Genie is private to your organisation
Your documents are protected:
Your documents are protected by ultra-secure 256-bit encryption
We are ISO27001 certified, so your data is secure
Organizational security:
You retain IP ownership of your documents and their information
You have full control over your data and who gets to see it
.png)