The Standard Form of Building Contract is the primary contractual document used for construction projects in Malta, designed to comply with Maltese construction law and regulations. It serves as a comprehensive agreement between employers and contractors, covering all essential aspects of construction projects including scope of works, payment terms, timelines, quality standards, and dispute resolution mechanisms. This document is particularly important in Malta's rapidly developing construction sector, where it provides a standardized approach to project delivery while incorporating local legal requirements and industry best practices. The contract is structured to accommodate various project sizes and types, from residential developments to commercial construction, and includes provisions for dealing with common construction issues such as variations, delays, and defects. It aligns with requirements set by the Building and Construction Authority of Malta and other relevant regulatory bodies.
Standard Form Of Building Contract for Malta
Create a bespoke document in minutes, or upload and review your own.
Thank you! Your submission has been received!
Oops! Something went wrong while submitting the form.
Get your first 2 documents free
Your data doesn't train Genie's AI
You keep IP ownership聽of your information
Key Requirements PROMPT example:
Standard Form Of Building Contract
"I need a Standard Form of Building Contract for a five-story commercial office development in Valletta, Malta, with construction starting March 2025, including specific provisions for heritage building requirements and BIM implementation."
Your data doesn't train Genie's AI
You keep IP ownership聽of your information
Thank you! Your submission has been received!
Oops! Something went wrong while submitting the form.
OR
Let tiktok成人版's market-leading legal AI identify missing terms, unusual language, compliance issues and more - in just seconds.
1. Parties: Identification and details of the Employer and the Contractor
2. Background: Context of the construction project and purpose of the agreement
3. Definitions and Interpretation: Definitions of key terms and rules for interpreting the contract
4. Contract Documents: Hierarchy and list of documents forming part of the contract
5. Contractor's Obligations: General and specific obligations of the Contractor including quality standards and workmanship
6. Employer's Obligations: General and specific obligations of the Employer including site access and payments
7. Architect/Engineer's Role: Powers, duties and authority of the appointed Architect/Engineer
8. Time and Programme: Project timeline, completion dates, and programming requirements
9. Contract Price and Payment: Payment terms, valuation procedures, and payment certificates
10. Variations: Procedures for handling changes to the works and price adjustments
11. Quality and Defects: Quality standards, testing procedures, and defects correction process
12. Health and Safety: Safety requirements and responsibilities aligned with Maltese regulations
13. Insurance and Indemnities: Required insurance coverage and indemnification obligations
14. Force Majeure: Provisions for unforeseen circumstances and their handling
15. Suspension and Termination: Rights and procedures for suspending or terminating the contract
16. Dispute Resolution: Procedures for resolving disputes including arbitration under Maltese law
17. Governing Law: Confirmation of Maltese law as governing law and jurisdiction
1. Performance Security: Requirements for performance bonds or guarantees, used for high-value projects
2. Environmental Protection: Specific environmental obligations, required for environmentally sensitive projects
3. Archaeological Findings: Procedures for handling archaeological discoveries, relevant for projects in historical areas
4. Nominated Subcontractors: Provisions for employer-nominated subcontractors, used when specific specialists are required
5. Cost Fluctuations: Provisions for adjusting prices due to market fluctuations, used in long-term projects
6. Concurrent Delays: Specific provisions for handling concurrent delays, used in complex projects
7. Building Information Modeling: BIM requirements and protocols, used in projects utilizing BIM technology
8. Heritage Building Requirements: Special provisions for working on protected buildings or monuments
1. Schedule 1: Contract Details: Key project information, contract sum, dates, and parties' details
2. Schedule 2: Contract Drawings: List and copies of all approved construction drawings
3. Schedule 3: Specifications: Detailed technical specifications for materials and workmanship
4. Schedule 4: Bill of Quantities: Itemized quantities and rates for the works
5. Schedule 5: Programme of Works: Detailed construction programme with milestones
6. Schedule 6: Site Information: Site details, conditions, and any known restrictions
7. Schedule 7: Forms of Bonds and Guarantees: Templates for required security documents
8. Schedule 8: Insurance Requirements: Detailed insurance requirements and minimum coverage
9. Appendix A: Health and Safety Requirements: Detailed health and safety procedures and requirements
10. Appendix B: Quality Control Procedures: Detailed quality control and testing requirements
11. Appendix C: Environmental Management Plan: Environmental protection measures and procedures
Authors
Relevant legal definitions
Clauses
Relevant Industries
Construction
Real Estate Development
Infrastructure
Commercial Property
Residential Development
Industrial Construction
Public Works
Healthcare Construction
Educational Facilities
Hospitality and Tourism
Retail Development
Maritime Infrastructure
Relevant Teams
Legal
Operations
Construction
Commercial
Procurement
Finance
Risk Management
Project Management
Technical Services
Quality Assurance
Health and Safety
Contract Administration
Relevant Roles
Project Manager
Construction Manager
Contract Administrator
Quantity Surveyor
Site Engineer
Architect
Legal Counsel
Commercial Director
Procurement Manager
Risk Manager
Construction Director
Development Manager
Technical Director
Operations Manager
Chief Executive Officer
Financial Controller
Health and Safety Manager
Quality Assurance Manager
Find the exact document you need
No items found.
骋别苍颈别鈥檚 Security Promise
Genie is the safest place to draft. Here鈥檚 how we prioritise your privacy and security.
Your documents are private:
We do not train on your data; 骋别苍颈别鈥檚 AI improves independently
All data stored on Genie is private to your organisation
Your documents are protected:
Your documents are protected by ultra-secure 256-bit encryption
We are ISO27001 certified, so your data is secure
Organizational security:
You retain IP ownership of your documents and their information
You have full control over your data and who gets to see it
.png)