The Turnkey Contract Agreement is a specialized construction contract used when an employer requires a single contractor to take full responsibility for delivering a complete, operational facility or project. This document is particularly suitable for complex projects in Malta where the employer wants to minimize their involvement in the day-to-day project execution and technical details. The agreement comprehensively covers all aspects from design through commissioning, incorporating requirements under Maltese law, including the Civil Code, Building Regulation Act, and environmental regulations. It's structured to provide clear allocation of responsibilities, risk management procedures, and detailed technical specifications, while ensuring compliance with local construction standards and planning requirements. The document is typically used for large-scale commercial, industrial, or infrastructure projects where the contractor's expertise in both design and construction is crucial for project success.
Turnkey Contract Agreement for Malta
Create a bespoke document in minutes, or upload and review your own.
Thank you! Your submission has been received!
Oops! Something went wrong while submitting the form.
Get your first 2 documents free
Your data doesn't train Genie's AI
You keep IP ownership聽of your information
Key Requirements PROMPT example:
Turnkey Contract Agreement
"I need a Turnkey Contract Agreement under Maltese law for the construction of a boutique hotel in Valletta, with project completion set for March 2025, including specific provisions for historical building preservation and sustainable tourism requirements."
Your data doesn't train Genie's AI
You keep IP ownership聽of your information
Thank you! Your submission has been received!
Oops! Something went wrong while submitting the form.
OR
Let tiktok成人版's market-leading legal AI identify missing terms, unusual language, compliance issues and more - in just seconds.
1. Parties: Identification and details of the contracting parties (employer/owner and contractor)
2. Background: Context of the agreement and brief description of the project
3. Definitions: Definitions of key terms used throughout the agreement
4. Scope of Works: Detailed description of the works to be performed, including design and construction obligations
5. Contract Price and Payment Terms: Fixed price, payment schedule, variations, and payment conditions
6. Time for Completion: Project timeline, completion date, and milestone dates
7. Contractor's Obligations: General and specific obligations of the contractor, including design, construction, and testing
8. Employer's Obligations: Responsibilities of the employer, including site access and permits
9. Quality and Standards: Required quality standards, inspections, and acceptance criteria
10. Testing and Commissioning: Procedures for testing, commissioning, and handover
11. Defects Liability: Warranty period, rectification of defects, and final acceptance
12. Changes and Variations: Procedures for handling changes to scope, price, or timeline
13. Force Majeure: Events beyond parties' control and their consequences
14. Insurance and Indemnity: Required insurance coverage and indemnification obligations
15. Termination: Grounds and procedures for contract termination
16. Disputes Resolution: Procedures for resolving disputes, including arbitration
17. Governing Law: Applicable law and jurisdiction
18. General Provisions: Standard boilerplate clauses including notices, assignment, and entire agreement
1. Performance Security: Requirements for performance bonds or guarantees, used when additional financial security is needed
2. Intellectual Property Rights: IP ownership and licenses, important when design or proprietary technology is involved
3. Environmental Compliance: Specific environmental obligations, needed for projects with significant environmental impact
4. Local Content Requirements: Requirements for local sourcing or employment, if required by law or project specifications
5. Interface Management: Procedures for managing interfaces with other contractors, needed for complex projects
6. Step-in Rights: Employer's right to take over work, important for critical infrastructure projects
7. Liquidated Damages: Pre-agreed damages for delay or performance failures, when specific metrics are crucial
8. Advance Payment: Terms for advance payments and their security, when advance funding is required
1. Schedule 1 - Scope of Works: Detailed technical specifications and drawings
2. Schedule 2 - Project Timeline: Detailed program of works and milestone dates
3. Schedule 3 - Payment Schedule: Detailed breakdown of payments and milestone payments
4. Schedule 4 - Site Information: Site details, access points, and existing conditions
5. Schedule 5 - Testing and Commissioning Procedures: Detailed procedures for testing and acceptance
6. Schedule 6 - Forms of Certificates: Templates for various certificates (completion, acceptance, etc.)
7. Schedule 7 - Key Personnel: List of key personnel and their roles
8. Schedule 8 - Required Insurances: Detailed insurance requirements and coverage levels
9. Schedule 9 - Performance Specifications: Detailed performance requirements and standards
10. Schedule 10 - Forms of Bonds and Guarantees: Templates for required bonds and guarantees
Authors
Relevant legal definitions
Clauses
Relevant Industries
Construction
Infrastructure Development
Real Estate
Industrial Manufacturing
Energy and Utilities
Healthcare Facilities
Hospitality and Tourism
Technology and Data Centers
Renewable Energy
Transportation
Educational Facilities
Waste Management
Manufacturing Facilities
Relevant Teams
Legal
Project Management
Construction
Commercial
Procurement
Finance
Operations
Technical
Risk Management
Quality Assurance
Compliance
Business Development
Facilities Management
Relevant Roles
Chief Executive Officer
Project Director
Construction Manager
Contract Manager
Legal Counsel
Project Manager
Commercial Director
Technical Director
Risk Manager
Procurement Manager
Finance Director
Operations Director
Development Manager
Facilities Manager
Compliance Officer
Cost Controller
Quality Assurance Manager
Find the exact document you need
Project Based Contract Agreement
A Maltese law-governed agreement establishing terms and conditions for project-based work between client and contractor.
find out more
Design Build Contract
A Maltese law-governed contract combining design and construction responsibilities under a single contractor's scope.
find out more
Construction Work Agreement
A Maltese law-governed agreement setting out terms and conditions for construction works between an employer and contractor, including scope, payment, and compliance with local building regulations.
find out more
Project Management Agreement
A Maltese law-governed agreement setting out terms for professional project management services, including scope, responsibilities, and commercial terms.
find out more
Building Work Agreement
A Maltese law-governed agreement setting out terms and conditions for construction work between an employer and contractor, ensuring compliance with local building regulations and standards.
find out more
Turnkey Contract Agreement
A Maltese law-governed agreement for the delivery of a complete, ready-to-use facility, covering design, construction, and commissioning under a single contractor's responsibility.
find out more
Renovation Agreement
A Maltese law-governed agreement establishing terms and conditions for property renovation works, including scope, payments, and regulatory compliance.
find out more
Demolition Agreement
A Maltese law-governed agreement setting out terms and conditions for demolition works, including regulatory compliance, safety measures, and contractor obligations.
find out more
Consortium Agreement Between Companies
A Maltese law-governed agreement establishing and regulating a formal consortium between multiple companies, outlining their rights, obligations, and collaborative framework.
find out more
General Construction Agreement
A Maltese law-governed agreement setting out terms and conditions for construction projects, including rights, obligations, and compliance with local building regulations.
find out more
Proof Of Concept Agreement
A Maltese law-governed agreement establishing terms and conditions for conducting and evaluating a proof of concept between technology providers and clients.
find out more
骋别苍颈别鈥檚 Security Promise
Genie is the safest place to draft. Here鈥檚 how we prioritise your privacy and security.
Your documents are private:
We do not train on your data; 骋别苍颈别鈥檚 AI improves independently
All data stored on Genie is private to your organisation
Your documents are protected:
Your documents are protected by ultra-secure 256-bit encryption
We are ISO27001 certified, so your data is secure
Organizational security:
You retain IP ownership of your documents and their information
You have full control over your data and who gets to see it
.png)