The General Contractor And Subcontractor Agreement is essential for construction and engineering projects in England and Wales where specialized work packages are delegated to subcontractors. This agreement establishes clear lines of responsibility, payment mechanisms, and performance standards while ensuring compliance with UK construction legislation. It protects both parties' interests by clearly defining scope, timelines, quality standards, and dispute resolution procedures. The document is particularly crucial for managing complex projects where multiple subcontractors are involved and clear contractual relationships need to be established.
Create a bespoke document in minutes, or upload and review your own.
Thank you! Your submission has been received!
Oops! Something went wrong while submitting the form.
Get your first 2 documents free
Your data doesn't train Genie's AI
You keep IP ownership of your information
Key Requirements PROMPT example:
General Contractor And Subcontractor Agreement
"I need a General Contractor And Subcontractor Agreement for a large-scale commercial building project in Manchester, where our main contractor will be working with multiple specialist subcontractors for electrical and HVAC installations, with work scheduled to commence in March 2025."
1. Parties: Identification and details of the General Contractor and Subcontractor
2. Background: Context of the agreement and relationship between parties
3. Definitions: Key terms used throughout the agreement
4. Scope of Work: Detailed description of services and works to be performed
5. Payment Terms: Payment amounts, schedules, and mechanisms including compliance with Construction Act requirements
6. Duration and Timeline: Project schedule, milestones, and completion dates
7. Health and Safety Obligations: Compliance with H&S regulations and responsibilities under CDM 2015
8. Insurance and Liability: Required insurance coverage and liability allocation
9. Termination: Conditions and procedures for contract termination
1. Performance Bonds: Requirements for performance bonds and financial security
2. Environmental Compliance: Environmental obligations and standards under Environmental Protection Act
3. Liquidated Damages: Predetermined damages for specific breaches of contract
4. Dispute Resolution: Specific procedures for resolving disputes including adjudication provisions
1. Schedule of Works: Detailed breakdown of work to be performed including specifications
2. Schedule of Rates: Agreed rates for various types of work and materials
3. Programme of Works: Detailed timeline and project schedule with key milestones
4. Insurance Certificates: Copies of required insurance policies and certificates
5. Health and Safety Plan: Detailed H&S procedures and requirements under CDM 2015
6. Quality Assurance Plan: Quality standards, inspection procedures and compliance requirements
7. Site Rules and Procedures: Specific rules for working on site and site management protocols
Authors
Relevant legal definitions
Clauses
Relevant Industries
Relevant Teams
Relevant Roles
Find the exact document you need
Subcontractor Payment Agreement
An England & Wales agreement outlining payment terms and conditions between contractors and subcontractors.
find out more
Subcontractor Hold Harmless Agreement
An England & Wales legal document allocating risk and indemnity between contractors and subcontractors in projects.
find out more
Nominated Subcontractor Contract
An England & Wales contract assigning specialist subcontractor duties under main contractor oversight.
find out more
Framing Subcontractor Agreement
A legal document from England & Wales granting power of attorney for financial and property affairs.
find out more
General Contractor And Subcontractor Agreement
A legally binding agreement under English and Welsh law defining the relationship and obligations between a general contractor and subcontractor in construction projects.
find out more
Marketing Subcontractor Agreement
A legal agreement under English and Welsh law governing the relationship between a marketing contractor and subcontractor for marketing services delivery.
find out more
Addendum To Subcontract Agreement
An English law document that amends an existing subcontract agreement, documenting agreed changes between main contractor and subcontractor.
find out more
Landscape Subcontractor Agreement
An England and Wales law agreement between main contractor and landscape subcontractor for landscaping works on construction projects.
find out more
Subcontractor Indemnification Agreement
An England and Wales law agreement establishing indemnification terms between a main contractor and subcontractor.
find out more
Hold Harmless Agreement For Contractors
A legal agreement under English and Welsh law that protects contracting parties from liability claims by establishing clear terms for risk allocation and indemnification.
find out more
Flooring Subcontractor Agreement
An England and Wales law-governed agreement between main contractor and flooring subcontractor covering works, payments, and obligations.
find out more
Prime Subcontractor Agreement
A contract under English and Welsh law governing the relationship between prime contractor and subcontractor for specific works or services.
find out more
Painting Subcontractor Agreement
An England and Wales-governed agreement between a main contractor and painting subcontractor, detailing painting services terms and conditions.
find out more
Roofing Subcontractor Contract
An England and Wales law-governed agreement between a main contractor and roofing subcontractor, setting out terms for specific roofing works.
find out more
Subcontractor Non Solicitation Agreement
An English law agreement preventing subcontractors from soliciting staff or clients from the primary contractor.
find out more
Transport Subcontractor Agreement
A legal agreement governed by English and Welsh law that sets out terms for transport subcontracting services.
find out more
Plumbing Subcontractor Agreement
An England and Wales law-governed agreement between a main contractor and plumbing subcontractor defining terms for plumbing works.
find out more
Security Subcontractor Agreement
A legal agreement under English and Welsh law governing the relationship between a main security contractor and their security subcontractor.
find out more
Software Subcontractor Agreement
An English law agreement governing the relationship between a main contractor and subcontractor for software development services.
find out more
Subcontract Lease Agreement
A legal agreement under English and Welsh law enabling a tenant to sublease property to another party, subject to head landlord approval.
find out more
Independent Subcontractor Agreement
A legally binding agreement under English and Welsh law that establishes the terms between a contractor and an independent subcontractor.
find out more
Independent Contractor Subcontractor Agreement
A legally binding agreement under English and Welsh law that establishes terms for subcontractor services to a main contractor.
find out more
Subcontractor Confidentiality Agreement
An English law agreement protecting confidential information shared between contractors and subcontractors.
find out more
Download our whitepaper on the future of AI in Legal
By providing your email address you are consenting to our Privacy Notice.
³Ò±ð²Ô¾±±ð’s Security Promise
Genie is the safest place to draft. Here’s how we prioritise your privacy and security.
Your documents are private:
We do not train on your data; ³Ò±ð²Ô¾±±ð’s AI improves independently
All data stored on Genie is private to your organisation
Your documents are protected:
Your documents are protected by ultra-secure 256-bit encryption
Our bank-grade security infrastructure undergoes regular external audits
We are ISO27001 certified, so your data is secure
Organizational security
You retain IP ownership of your documents
You have full control over your data and who gets to see it
Innovation in privacy:
Genie partnered with the Computational Privacy Department at Imperial College London
Together, we ran a £1 million research project on privacy and anonymity in legal contracts
Want to know more?
Visit our for more details and real-time security updates.
Read our Privacy Policy.
