The Subcontractor Contract Form is essential for businesses operating in Ireland that need to formalize arrangements with subcontractors for specific projects or ongoing services. This document is particularly crucial in industries such as construction, where the Construction Contracts Act 2013 mandates certain provisions regarding payment practices and dispute resolution. The contract form includes comprehensive terms covering scope of work, payment schedules, performance requirements, and risk allocation, while ensuring compliance with Irish employment, safety, and industry-specific regulations. It's designed to protect both the main contractor's and subcontractor's interests while establishing clear accountability and performance standards. The document is typically used when a main contractor needs to delegate specific portions of work to specialized subcontractors while maintaining overall project responsibility to the end client.
Your data doesn't train Genie's AI
You keep IP ownership聽of your information
Thank you! Your submission has been received!
Oops! Something went wrong while submitting the form.
OR
Let tiktok成人版's market-leading legal AI identify missing terms, unusual language, compliance issues and more - in just seconds.
1. Parties: Identifies and provides full legal details of the main contractor and subcontractor
2. Background: Sets out the context of the agreement, including reference to the main contract and the contractor's authority to subcontract
3. Definitions: Defines key terms used throughout the agreement
4. Scope of Works: Detailed description of the works or services to be provided by the subcontractor
5. Subcontractor Obligations: Core responsibilities and standards of work expected from the subcontractor
6. Contractor Obligations: Main contractor's responsibilities and commitments
7. Programme and Timing: Timeline, milestones, and completion dates for the works
8. Payment Terms: Payment amounts, schedule, and mechanisms, including compliance with Construction Contracts Act 2013
9. Health and Safety: Safety requirements and responsibilities under Irish health and safety legislation
10. Insurance and Liability: Required insurance coverage and allocation of risks
11. Termination: Grounds and procedures for contract termination
12. Dispute Resolution: Procedures for handling disputes, including statutory adjudication requirements
13. Governing Law: Confirmation of Irish law as governing law and jurisdiction
1. Intellectual Property: Required when the works involve creation or use of intellectual property
2. Confidentiality: Needed when sensitive information will be shared
3. Environmental Requirements: Include for works with environmental impacts or requirements
4. Quality Assurance: For projects requiring specific quality standards or certifications
5. Performance Bond: When additional security for performance is required
6. Data Protection: Required when personal data processing is involved
7. Force Majeure: Include for longer-term contracts or where specific risk allocation is needed
8. Step-in Rights: For critical projects where contractor may need to take over subcontractor's work
1. Schedule 1 - Scope of Works: Detailed technical specifications and requirements
2. Schedule 2 - Programme of Works: Detailed timeline and milestone dates
3. Schedule 3 - Payment Schedule: Breakdown of payments, rates, and payment conditions
4. Schedule 4 - Key Personnel: List of key staff and their roles
5. Schedule 5 - Required Insurances: Detailed insurance requirements and minimum coverage
6. Schedule 6 - Site Rules and Procedures: Specific site requirements and operational procedures
7. Appendix A - Form of Payment Application: Standard form for payment applications
8. Appendix B - Health and Safety Requirements: Detailed safety procedures and requirements
Authors
Relevant legal definitions
Clauses
Relevant Industries
Construction
Engineering
Information Technology
Professional Services
Manufacturing
Facilities Management
Infrastructure
Telecommunications
Energy
Industrial Services
Relevant Teams
Legal
Procurement
Operations
Commercial
Finance
Risk Management
Health and Safety
Project Management
Contract Administration
Technical Services
Relevant Roles
Project Manager
Construction Manager
Procurement Manager
Contract Manager
Legal Counsel
Commercial Director
Operations Manager
Site Supervisor
Risk Manager
Quantity Surveyor
Chief Financial Officer
Technical Director
Compliance Officer
Health and Safety Manager
Find the exact document you need
Renovation Contract Agreement
An Irish law-governed agreement setting out terms and conditions for property renovation works between a property owner and contractor.
find out more
Electrical Contractor Agreement
An Irish law-governed agreement between an electrical contractor and client for electrical installation, maintenance, or repair services, ensuring compliance with Irish electrical safety standards and regulations.
find out more
Basic Contractor Agreement
An Irish law-governed agreement establishing the terms and conditions between a company and an independent contractor, ensuring clear definition of services and maintaining contractor status.
find out more
Agreement To Rescind Contract
An Irish law-governed agreement that formally terminates an existing contract by mutual consent of the parties.
find out more
Simple Building Contract
An Irish law-governed building contract for small to medium construction projects, establishing rights and obligations between property owners and contractors.
find out more
Construction Company Contract
Irish construction company contract template compliant with local construction laws and regulations, suitable for various construction projects in Ireland.
find out more
Builder Client Contract
An Irish law-governed contract between a builder and client defining construction works, payments, and obligations under Irish construction regulations.
find out more
Labour Contract Form
Standard Irish labour contract outlining employment terms and conditions in compliance with Irish employment law.
find out more
Short Independent Contractor Agreement
An Irish law-governed short-form agreement for engaging independent contractors, balancing legal compliance with practical business needs.
find out more
Contractor Work Contract
An Irish law-governed agreement establishing the terms and conditions between a client and an independent contractor, defining services, payments, and obligations while maintaining contractor independence.
find out more
Indemnity Agreement (Construction)
Irish law construction indemnity agreement establishing risk allocation and protection mechanisms between construction project parties.
find out more
Indemnification Agreement (Construction)
An Irish law-governed agreement establishing indemnification obligations and risk allocation between parties in construction projects.
find out more
Contractor Contract Agreement
An Irish law-governed agreement establishing terms and conditions between a company and an independent contractor, ensuring clear definition of services, payments, and obligations.
find out more
Construction Contract Between Owner And Contractor
An Irish law-governed construction contract between property owner and contractor, compliant with the Construction Contracts Act 2013 and Irish building regulations.
find out more
Non Compete With Independent Contractor
An Irish law-compliant Non-Compete Agreement for independent contractors, protecting business interests while ensuring reasonable restrictions.
find out more
Exclusive Subcontractor Agreement
An Irish law-governed agreement establishing exclusive subcontracting arrangements between a main contractor and subcontractor, defining service delivery and compliance requirements.
find out more
General Contractor Contract Agreement
Irish law-governed construction agreement between an employer and general contractor, compliant with Construction Contracts Act 2013 and Irish building regulations.
find out more
Short Form Contractor Agreement
An Irish law-governed contractor agreement establishing key terms for independent contractor engagements while ensuring compliance with Irish legal requirements.
find out more
Cleaning Contractor Agreement
An Irish law-governed agreement between a client and cleaning contractor establishing terms for professional cleaning services provision.
find out more
House Renovation Contract
An Irish law-governed contract establishing terms and conditions for house renovation works between property owners and contractors.
find out more
Freelance Contractor Agreement
An Irish law-governed agreement establishing the terms and conditions between a company and an independent contractor, defining services, payments, and mutual obligations.
find out more
Subcontractor Service Agreement
An Irish law-governed agreement establishing terms and conditions between a contractor and subcontractor for service provision.
find out more
Sole Trader Contract
An Irish law-governed contract template for engaging sole traders as independent contractors, ensuring proper business relationship structure and regulatory compliance.
find out more
Simple Payment Agreement Contract
An Irish law-governed agreement establishing payment terms, schedules, and obligations between parties, with enforcement mechanisms under Irish commercial law.
find out more
Labour Hire Contract
An Irish law-governed Labour Hire Contract establishing terms between a labour hire agency, worker, and host employer, ensuring compliance with Irish employment legislation.
find out more
Labour Hire Agreement
An Irish law-governed agreement between a labour hire agency and client company for the provision of temporary workers, ensuring compliance with Irish employment legislation.
find out more
Driver Contractor Agreement
An Irish law-governed agreement between a company and an independent driver contractor, establishing terms for transportation services and regulatory compliance.
find out more
Domestic Subcontract Agreement
An Irish law-governed agreement between main contractor and subcontractor for residential construction works, incorporating key requirements of Irish construction legislation.
find out more
Contractor Service Agreement
An Irish law-governed agreement establishing terms and conditions between a company and an independent contractor for the provision of specific services.
find out more
Consulting Agreement Contract
An Irish law-governed agreement establishing the terms and conditions between a client and consultant for professional consulting services.
find out more
Self Employed Consultant Agreement
An Irish law-governed agreement establishing the terms and conditions between a client and a self-employed consultant, defining services, payments, and professional obligations.
find out more
Salon Contract For Employees
An Irish law-governed employment contract for salon staff, outlining terms, conditions, and industry-specific requirements for beauty and wellness professionals.
find out more
Part Time Contractor Agreement
An Irish law-governed agreement establishing terms and conditions for part-time contractor engagement, defining services, payments, and legal obligations.
find out more
Independent Sales Contract
An Irish law-governed agreement establishing terms between a company and independent sales agent, including commission structures and territorial rights.
find out more
Home Remodel Contract
An Irish law-governed contract for home renovation projects, establishing terms between homeowners and contractors while ensuring compliance with Irish construction regulations.
find out more
Framework Agreement Contract
An Irish law-governed agreement establishing terms for ongoing commercial relationships and future call-off contracts.
find out more
Confidentiality Agreement For Independent Contractors
Irish law-compliant confidentiality agreement for independent contractors, incorporating GDPR and local data protection requirements.
find out more
Binding Agreement Contract
An Irish law-governed binding agreement that establishes legal terms and conditions between parties, ensuring enforceability and compliance with Irish legal requirements.
find out more
Electrical Contract Form
An Irish-law electrical contract form for electrical installation and maintenance works, compliant with Irish safety regulations and construction laws.
find out more
Subcontractor Contract Form
An Irish law-governed agreement establishing terms and conditions between a main contractor and subcontractor for the provision of specified works or services.
find out more
骋别苍颈别鈥檚 Security Promise
Genie is the safest place to draft. Here鈥檚 how we prioritise your privacy and security.
Your documents are private:
We do not train on your data; 骋别苍颈别鈥檚 AI improves independently
All data stored on Genie is private to your organisation
Your documents are protected:
Your documents are protected by ultra-secure 256-bit encryption
We are ISO27001 certified, so your data is secure
Organizational security:
You retain IP ownership of your documents and their information
You have full control over your data and who gets to see it
.png)