The Standard Construction Agreement serves as a foundational legal document for construction projects in Malaysia, designed to meet the requirements of the Malaysian construction industry regulatory framework. This agreement is typically used for both commercial and residential construction projects where a clear contractual relationship needs to be established between the project owner/employer and the contractor. It encompasses essential elements required by Malaysian law, including CIDB requirements, payment provisions under CIPAA 2012, and local building regulations. The document includes comprehensive provisions for project execution, risk allocation, quality control, and dispute resolution, making it suitable for various scales of construction projects while ensuring compliance with Malaysian construction law and industry standards.
Your data doesn't train Genie's AI
You keep IP ownership聽of your information
Thank you! Your submission has been received!
Oops! Something went wrong while submitting the form.
OR
Let tiktok成人版's market-leading legal AI identify missing terms, unusual language, compliance issues and more - in just seconds.
1. Parties: Identification and details of the contracting parties (employer/owner and contractor)
2. Background: Context of the agreement and brief project overview
3. Definitions and Interpretation: Definitions of key terms and interpretation rules for the agreement
4. Scope of Works: Detailed description of the construction works to be performed
5. Contract Sum and Payment Terms: Agreement price, payment schedule, and payment mechanisms
6. Duration and Programme: Project timeline, completion date, and milestone requirements
7. Contractor's Obligations: Primary responsibilities and duties of the contractor
8. Employer's Obligations: Primary responsibilities and duties of the employer
9. Variations: Procedures for handling changes to scope, price, or timeline
10. Quality and Standards: Required quality standards, inspections, and approval processes
11. Health, Safety and Environment: Safety requirements and environmental compliance obligations
12. Insurance and Indemnities: Required insurance coverage and indemnification provisions
13. Defects Liability: Defects liability period and rectification procedures
14. Termination: Grounds and procedures for contract termination
15. Dispute Resolution: Procedures for resolving disputes including mediation and arbitration
16. General Provisions: Standard legal provisions including notices, governing law, and assignment
1. Performance Security: Requirements for performance bonds or guarantees, used for high-value projects
2. Intellectual Property Rights: IP provisions when design or innovative construction methods are involved
3. Liquidated Damages: Pre-determined damages for delay or performance failure, used in time-critical projects
4. Force Majeure: Provisions for unforeseen circumstances, particularly relevant in long-term projects
5. Confidentiality: Confidentiality obligations when sensitive information is involved
6. Anti-Corruption: Anti-bribery and corruption provisions for public or high-value projects
7. Step-In Rights: Employer's right to take over works, used in critical infrastructure projects
8. Materials and Equipment: Specific provisions for supply and ownership of materials, used in projects with significant material components
1. Schedule 1 - Scope of Works: Detailed technical specifications and drawings
2. Schedule 2 - Contract Price Breakdown: Detailed breakdown of contract sum and bill of quantities
3. Schedule 3 - Project Timeline: Detailed project schedule with milestones
4. Schedule 4 - Payment Schedule: Detailed payment terms and milestone payments
5. Schedule 5 - Site Information: Site details, access requirements, and existing conditions
6. Schedule 6 - Required Insurances: Details of required insurance coverage
7. Schedule 7 - Key Personnel: List of key project personnel and their roles
8. Schedule 8 - Forms and Certificates: Standard forms for variations, completion certificates, etc.
9. Appendix A - Technical Drawings: Complete set of construction drawings
10. Appendix B - Quality Assurance Plan: Detailed quality control procedures and requirements
Relevant legal definitions
Clauses
Relevant Industries
Construction
Real Estate Development
Infrastructure
Commercial Property
Residential Property
Industrial Construction
Public Works
Urban Development
Property Management
Civil Engineering
Relevant Teams
Legal
Construction
Project Management
Operations
Commercial
Procurement
Risk and Compliance
Property Development
Engineering
Contract Administration
Relevant Roles
Construction Manager
Project Manager
Contract Administrator
Legal Counsel
Property Developer
Construction Director
Site Manager
Quantity Surveyor
Project Engineer
Commercial Manager
Risk Manager
Procurement Manager
Operations Director
Development Manager
Compliance Officer
Find the exact document you need
Home Builder Subcontractor Agreement
A Malaysian law-governed agreement between main contractor and subcontractor for residential construction works, complying with local construction and housing development regulations.
find out more
Contractor Service Contract
Malaysian law-governed agreement establishing terms between a company and independent contractor, defining service provisions and relationship parameters.
find out more
Independent Contractor Therapist Agreement
Malaysian-law governed agreement establishing an independent contractor relationship between a healthcare facility and a therapist.
find out more
Contractor Architect Agreement
A Malaysian law-governed agreement between a client and an architect contractor defining architectural services, obligations, and commercial terms.
find out more
Contract For Work For Hire
A Malaysian law-governed agreement establishing terms for commissioned work, including ownership transfer, payment, and delivery obligations.
find out more
Simple Building Contract
A Malaysian law-governed construction agreement for straightforward building projects, establishing key terms between employer and contractor.
find out more
Basic Independent Contractor Agreement
A Malaysian law-governed agreement establishing the terms and conditions between a business and an independent contractor, ensuring clear definition of services and compliance with local regulations.
find out more
Self Employed Service Agreement
A Malaysian law-governed agreement establishing an independent contractor relationship between a service provider and client company, defining services, terms, and obligations.
find out more
Contractor Deposit Agreement
A Malaysian law-governed agreement establishing terms for contractor deposits in construction projects, including payment, holding, and release conditions.
find out more
Developer Contractor Agreement
Malaysian-law governed agreement for engaging software development contractors, defining service terms and protecting both parties' interests.
find out more
Home Contractor Contract
A Malaysian law-governed contract between homeowner and contractor for residential construction works, including terms, conditions, and regulatory compliance requirements.
find out more
Standard Independent Contractor Contract
A Malaysian law-governed agreement establishing terms and conditions between a company and an independent contractor for professional services.
find out more
Agreement Between Owner And Electrical Contractor
A Malaysian law-governed agreement between property owner and electrical contractor defining terms, scope, and compliance requirements for electrical installation works.
find out more
Service Of Work Contract
A Malaysian law-governed agreement establishing terms and conditions for service provision between a service provider and client.
find out more
Residential Building Contract Agreement
A Malaysian law-governed agreement between property owner and contractor for residential construction works, ensuring compliance with local construction regulations and standards.
find out more
Agreement Between Owner And Labour Contractor
A Malaysian law-governed agreement between project owners and labor contractors establishing terms for workforce services and regulatory compliance.
find out more
Massage Contractor Agreement
A Malaysian law-governed agreement establishing an independent contractor relationship between a business and a massage therapist, defining service terms and operational requirements.
find out more
Short Form Contractor Agreement
A streamlined contractor agreement template for Malaysian jurisdiction, designed for engaging independent contractors or service providers.
find out more
Home Painting Contract
A Malaysian law-governed contract for residential painting services, establishing terms between contractors and property owners.
find out more
Home Improvement Agreement
A Malaysian law-governed agreement between homeowner and contractor for residential improvement works, detailing project scope, terms, and obligations.
find out more
Freelance Contractor Agreement
A Malaysian law-governed agreement establishing terms between a client and freelance contractor, defining services, payments, and obligations.
find out more
Subcontractor Employment Agreement
Malaysian-law governed agreement establishing subcontractor relationship and terms of service provision.
find out more
Simple Payment Agreement Contract
A Malaysian law-governed agreement establishing payment terms and obligations between parties.
find out more
Independent Contractor And Non Compete
Malaysian law-compliant agreement for engaging independent contractors with non-compete provisions to protect business interests.
find out more
Contractor Service Agreement
A Malaysian law-governed agreement establishing terms and conditions between a client company and an independent contractor for professional services.
find out more
Consulting Agreement Contract
A Malaysian law-governed agreement defining the terms and conditions between a consultant and client, including service scope, payments, and obligations.
find out more
Standard Form Of Contract For Maintenance And Renovation Works
A Malaysian standard form contract template for maintenance and renovation works, establishing terms and conditions between property owners and contractors.
find out more
Standard Builders Contract
A Malaysian law-governed construction contract defining the relationship between employer and contractor for building projects, aligned with CIDB requirements.
find out more
Simple Contractor Contract
A Malaysian law-governed contractor agreement establishing independent service provider relationships while ensuring legal compliance and protecting both parties' interests.
find out more
Self Employed Cleaner Contract
Malaysian-compliant contract template for engaging self-employed cleaning contractors, establishing service terms and independent contractor status.
find out more
Sales Subcontractor Agreement
Malaysian-law governed agreement establishing terms for sales subcontractor relationships, including commission structures, territories, and performance requirements.
find out more
Percentage Agreement Contract
A Malaysian law-governed agreement establishing percentage-based commercial terms between parties, including calculation methods and payment structures.
find out more
Painting Subcontractor Contract
A Malaysian law-governed contract establishing terms and conditions for painting subcontractor works in construction projects.
find out more
Part Time Contractor Agreement
Malaysian-law governed agreement for engaging part-time independent contractors, defining service terms and maintaining contractor independence.
find out more
General Contract For Services Agreement
A Malaysian law-governed agreement establishing terms and conditions for service provision between a provider and client.
find out more
General Contract Agreement Between Two Parties
A versatile contract template under Malaysian law establishing legal terms and conditions between two contracting parties.
find out more
Contract For Cleaning Services Agreement
A Malaysian law-governed agreement establishing terms and conditions for professional cleaning services between service providers and clients.
find out more
Construction Service Contract
A Malaysian law-governed agreement establishing terms and conditions for construction services between an employer and contractor.
find out more
Contract Agreement For Interior Works
A Malaysian law-governed agreement establishing terms and conditions for interior works projects, including scope, payments, and obligations of all parties.
find out more
Contractor Non Solicitation Agreement
A Malaysian law-governed agreement preventing contractors from soliciting company employees, clients, or customers during and after their engagement.
find out more
骋别苍颈别鈥檚 Security Promise
Genie is the safest place to draft. Here鈥檚 how we prioritise your privacy and security.
Your documents are private:
We do not train on your data; 骋别苍颈别鈥檚 AI improves independently
All data stored on Genie is private to your organisation
Your documents are protected:
Your documents are protected by ultra-secure 256-bit encryption
We are ISO27001 certified, so your data is secure
Organizational security:
You retain IP ownership of your documents and their information
You have full control over your data and who gets to see it
.png)