The Construction Agreement is a fundamental legal document used in the Philippines when engaging a contractor to perform construction works. It serves as the primary contract document that governs the relationship between the property owner/employer and the contractor, establishing their respective rights, obligations, and responsibilities throughout the construction project. This agreement is essential for any construction project in the Philippines, whether residential, commercial, or industrial, and must comply with various Philippine laws including the Civil Code, the National Building Code, and construction industry regulations. The document typically includes detailed specifications about the project scope, timeline, payment terms, quality standards, and dispute resolution mechanisms, while incorporating requirements from relevant government agencies such as the Department of Public Works and Highways (DPWH) and local government units.
Your data doesn't train Genie's AI
You keep IP ownership聽of your information
Thank you! Your submission has been received!
Oops! Something went wrong while submitting the form.
OR
Let tiktok成人版's market-leading legal AI identify missing terms, unusual language, compliance issues and more - in just seconds.
1. Parties: Identification of the Owner/Employer and the Contractor, including their complete legal names, addresses, and registration details
2. Background: Context of the agreement, including brief description of the project and the parties' intentions
3. Definitions: Definitions of key terms used throughout the agreement
4. Scope of Work: Detailed description of the construction work to be performed, including general obligations of the contractor
5. Contract Price: Total contract sum, payment terms, payment schedule, and conditions for payment
6. Project Timeline: Commencement date, completion date, project milestones, and provisions for extensions of time
7. Materials and Workmanship: Quality standards, specifications for materials, and workmanship requirements
8. Contractor's Obligations: Specific responsibilities including labor, equipment, permits, and compliance with laws
9. Owner's Obligations: Responsibilities of the owner including site access, permits, and approvals
10. Supervision and Inspection: Rights and procedures for supervision, inspection, and approval of work
11. Variations and Changes: Procedures for handling changes to scope, specifications, or other contract terms
12. Safety and Environmental Requirements: Safety standards, environmental compliance, and related obligations
13. Insurance and Bonds: Required insurance coverage and performance bonds
14. Warranties and Defects Liability: Warranty period, defects liability period, and remedy of defects
15. Termination: Grounds and procedures for contract termination by either party
16. Dispute Resolution: Procedures for resolving disputes, including mediation and arbitration
17. General Provisions: Standard legal provisions including governing law, notices, and assignment
1. Intellectual Property Rights: Provisions regarding ownership of designs and technical documents, relevant for projects involving custom designs or innovative solutions
2. Force Majeure: Provisions for unforeseen circumstances, particularly relevant in areas prone to natural disasters
3. Liquidated Damages: Specific provisions for damages in case of delay or default, optional but commonly included
4. Retention Money: Provisions for withholding portion of payment as security, used in larger projects
5. Subcontracting: Rules and conditions for subcontracting, needed if subcontractors will be involved
6. Site Conditions: Specific provisions regarding site conditions and underground works, relevant for complex construction sites
7. Equipment and Temporary Works: Provisions regarding construction equipment and temporary structures, relevant for larger projects
8. Testing and Commissioning: Detailed testing requirements, relevant for technical installations
9. Environmental Management Plan: Detailed environmental requirements, necessary for environmentally sensitive projects
1. Schedule A - Technical Specifications: Detailed technical specifications of the construction work
2. Schedule B - Construction Drawings: Approved architectural and engineering drawings
3. Schedule C - Bill of Quantities: Detailed breakdown of quantities and prices
4. Schedule D - Construction Schedule: Detailed timeline of construction activities and milestones
5. Schedule E - Payment Schedule: Detailed breakdown of payment terms and milestone payments
6. Schedule F - List of Approved Subcontractors: List of pre-approved subcontractors if applicable
7. Schedule G - Site Plan and Access Details: Site layout, access points, and logistics information
8. Schedule H - Quality Assurance Plan: Detailed quality control procedures and requirements
9. Schedule I - Safety Management Plan: Detailed safety procedures and requirements
10. Appendix 1 - Forms and Certificates: Standard forms for applications, certificates, and notices
11. Appendix 2 - Insurance Requirements: Detailed insurance specifications and requirements
Authors
Relevant legal definitions
Clauses
Relevant Industries
Construction
Real Estate Development
Infrastructure
Commercial Property
Residential Property
Industrial Development
Hospitality
Retail
Healthcare
Education
Manufacturing
Energy
Transportation
Relevant Teams
Legal
Operations
Construction
Project Management
Procurement
Finance
Risk & Compliance
Property Development
Facilities Management
Quality Control
Health & Safety
Engineering
Architecture
Contract Administration
Relevant Roles
Construction Manager
Project Manager
Contract Administrator
Legal Counsel
Quantity Surveyor
Site Engineer
Architect
Structural Engineer
Procurement Manager
Finance Director
Operations Director
Risk Manager
Compliance Officer
Property Developer
Facilities Manager
Construction Site Supervisor
Quality Control Manager
Health and Safety Officer
Find the exact document you need
Agreement Between Builder And Labour Contractor
A Philippine-law governed agreement between a Builder and Labour Contractor establishing terms for construction workforce services, including responsibilities, payments, and compliance requirements.
find out more
Contract Between Employer And Contractor
A Philippine law-governed agreement establishing terms and conditions between an employer and contractor, defining scope of work, payments, and legal obligations.
find out more
Agreement With Builder For (Construction)
A Philippine law-governed agreement between property owner and builder setting terms for construction works, including scope, payments, and compliance requirements.
find out more
Independent Contractor Therapist Agreement
A Philippine law-governed agreement establishing the professional relationship between a healthcare facility and an independent contractor therapist, outlining service terms and compliance requirements.
find out more
Contractor To Contractor Agreement
A Philippine law-governed agreement establishing terms and conditions between two independent contractors for business collaboration and service provision.
find out more
Freelance Independent Contractor Agreement
A Philippine law-governed agreement establishing the terms and conditions between a client and an independent contractor, defining services, payments, and legal obligations.
find out more
Contractor Agreement For House (Construction)
A Philippine law-governed agreement between property owner and contractor for residential house construction, outlining construction terms, specifications, and obligations.
find out more
Contractor Work Contract
Philippine-law governed agreement establishing and regulating independent contractor relationships, defining work scope, terms, and obligations.
find out more
Developer Contractor Agreement
A Philippine law-governed agreement establishing terms and conditions between a client and software developer contractor, ensuring clear independent contractor status and protecting both parties' interests.
find out more
Standard Renovation Contract
A comprehensive renovation agreement for use in the Philippines, establishing terms between property owners and contractors while ensuring compliance with Philippine construction laws.
find out more
Agreement Between Owner And Electrical Contractor
A Philippine law-governed agreement between property owners and electrical contractors for electrical works, compliant with national electrical and construction regulations.
find out more
Contractor Lease Agreement
A specialized lease agreement for contractors operating in the Philippines, combining property rental terms with construction-specific provisions under Philippine law.
find out more
House Building Contract Agreement
A Philippine law-governed contract between property owner and contractor for residential house construction, detailing construction terms, payments, and obligations.
find out more
Generic Contractor Agreement
A Philippine law-governed agreement establishing terms and conditions between a client and independent contractor, ensuring legal compliance and clear relationship definition.
find out more
Independent Service Contract
A Philippine law-governed agreement establishing terms and conditions between a client and independent contractor for professional services provision.
find out more
Professional Services Subcontractor Agreement
A Philippine law-governed agreement between a contractor and subcontractor for professional services delivery, defining service scope, terms, and compliance requirements.
find out more
Standard Employment Contract Form
A comprehensive employment contract template compliant with Philippine labor laws, establishing terms and conditions of employment between employer and employee.
find out more
Short Form Contractor Agreement
A streamlined contractor agreement under Philippine law that establishes the terms of engagement between a company and an independent contractor.
find out more
House Renovation Contract
A Philippine-law governed contract for residential renovation works, establishing terms between homeowner and contractor including scope, payments, and quality standards.
find out more
Subcontractor Employment Agreement
A Philippine-compliant agreement establishing terms and conditions for subcontractor employment relationships, aligned with local labor laws and DOLE regulations.
find out more
Painting Contract Agreement
A Philippine law-governed agreement establishing terms and conditions between a painting contractor and client for painting services.
find out more
Driver Contractor Agreement
A Philippine law-governed agreement establishing terms between a company and an independent driver contractor, defining service conditions and operational requirements.
find out more
Contractor Service Agreement
A Philippine law-governed agreement establishing terms and conditions between a client and independent contractor, defining service scope, payment terms, and contractor status.
find out more
Consulting Agreement Contract
A Philippine law-governed agreement establishing terms and conditions between a client and consultant for professional consulting services.
find out more
Standard Builders Contract
A Philippine law-governed construction agreement between owner and contractor, establishing terms for construction works while ensuring compliance with local regulations.
find out more
Simple Engineering Contract
A standardized engineering contract template for Philippines-based projects, incorporating local legal requirements and engineering standards.
find out more
Simple Handyman Contract
A Philippine law-compliant contract establishing terms between a handyman and property owner for maintenance or repair services.
find out more
Salon Contract For Employees
A Philippine-compliant employment agreement for salon industry workers, establishing terms, conditions, and professional standards for salon employment relationships.
find out more
Preferred Contractor Agreement
A Philippine law-governed agreement establishing a preferred independent contractor relationship, defining service terms and maintaining contractor independence while ensuring legal compliance.
find out more
Percentage Agreement Contract
A Philippine law-governed agreement establishing percentage-based payment terms and conditions between contracting parties for revenue sharing, commissions, or profit-sharing arrangements.
find out more
Painting Subcontractor Contract
A Philippine law-governed agreement between a main contractor and painting subcontractor defining terms for painting works execution, including quality standards and payment terms.
find out more
Part Time Contractor Agreement
A Philippine law-governed agreement establishing terms and conditions between a company and a part-time independent contractor.
find out more
Non Profit Contractor Agreement
A Philippine law-governed agreement between a non-profit organization and an independent contractor, defining their working relationship and mutual obligations.
find out more
Independent Employment Agreement
A Philippine law-governed agreement establishing terms between a company and independent contractor, ensuring legal compliance while protecting both parties' interests.
find out more
General Contract Agreement Between Two Parties
A general contract agreement template compliant with Philippine law, designed for establishing legally binding agreements between two parties.
find out more
Fence Contract Agreement
A legally binding agreement under Philippine law that governs the terms and conditions for fence construction or installation between a property owner and contractor.
find out more
Contract Agreement For Interior Works
A Philippine law-governed agreement establishing terms and conditions for interior construction and renovation works between contracting parties.
find out more
Construction Service Contract
A Philippine law-governed agreement establishing terms and conditions between an owner and contractor for construction services, incorporating local construction and safety regulations.
find out more
Carpenter Contract Agreement
A Philippine-law governed agreement establishing terms and conditions between a carpenter and client for carpentry services, ensuring compliance with local labor and construction regulations.
find out more
Basic Simple Subcontractor Agreement
A Philippine law-governed agreement establishing terms and conditions between a main contractor and subcontractor for delegated work or services.
find out more
骋别苍颈别鈥檚 Security Promise
Genie is the safest place to draft. Here鈥檚 how we prioritise your privacy and security.
Your documents are private:
We do not train on your data; 骋别苍颈别鈥檚 AI improves independently
All data stored on Genie is private to your organisation
Your documents are protected:
Your documents are protected by ultra-secure 256-bit encryption
We are ISO27001 certified, so your data is secure
Organizational security:
You retain IP ownership of your documents and their information
You have full control over your data and who gets to see it
.png)