The General Contractor Agreement With Owner is a fundamental document in Singapore's construction industry, essential for any significant building or renovation project. This agreement is designed to comply with Singapore's stringent construction regulations, including the Building Control Act and Security of Payment Act. It's typically used when a property owner engages a general contractor to oversee and execute construction work, establishing clear terms for project scope, payment schedules, quality standards, and risk allocation. The agreement incorporates specific requirements for contractor licensing, workplace safety, and mandatory insurance coverage under Singapore law.
Your data doesn't train Genie's AI
You keep IP ownership聽of your information
Thank you! Your submission has been received!
Oops! Something went wrong while submitting the form.
OR
Let tiktok成人版's market-leading legal AI identify missing terms, unusual language, compliance issues and more - in just seconds.
1. Parties: Identification and details of the Owner and General Contractor
2. Background: Context of the agreement and project overview
3. Definitions: Key terms used throughout the agreement
4. Scope of Work: Detailed description of construction work to be performed
5. Contract Price and Payment Terms: Agreement on compensation and payment schedule
6. Project Timeline: Construction schedule, milestones, and completion dates
7. Contractor's Obligations: Responsibilities and duties of the contractor including compliance with Building Control Act and Workplace Safety requirements
8. Owner's Obligations: Responsibilities and duties of the owner
9. Insurance and Indemnity: Required insurance coverage and indemnification provisions
10. Termination: Conditions and procedures for contract termination
1. Financing Arrangements: Terms regarding project financing and payment security arrangements
2. Environmental Compliance: Specific environmental requirements under Environmental Protection and Management Act
3. Liquidated Damages: Predetermined damages for specific breaches of contract terms
4. Alternative Dispute Resolution: Mediation or arbitration procedures for dispute resolution
1. Schedule A - Project Specifications: Detailed technical specifications and drawings
2. Schedule B - Bill of Quantities: Itemized list of materials and quantities
3. Schedule C - Payment Schedule: Detailed breakdown of payment milestones
4. Schedule D - Project Timeline: Detailed project schedule with milestones
5. Schedule E - Insurance Requirements: Specific insurance coverage requirements
6. Appendix 1 - Site Plans: Construction site plans and drawings
7. Appendix 2 - Permits and Licenses: Copies of required permits and licenses
Relevant legal definitions
Clauses
Relevant Industries
Relevant Teams
Relevant Roles
Find the exact document you need
Subcontractor Service Agreement
A Singapore-law governed agreement defining terms and conditions for subcontractor services, including scope, payment, and compliance requirements.
Download
Subcontractor Employment Agreement
A Singapore-law governed agreement establishing terms and conditions between a company and subcontractor for provision of services.
Download
Sole Trader Contract
A Singapore-law governed contract establishing the legal framework for sole trader business operations and compliance requirements.
Download
Simple Subcontractor Contract
A Singapore-law governed agreement between contractor and subcontractor defining work scope, terms, and obligations.
Download
Simple Payment Agreement Contract
A Singapore law-governed agreement establishing payment terms and obligations between parties.
Download
Residential Contractor Agreement
A legally binding agreement under Singapore law between property owners and contractors for residential construction or renovation works.
Download
Pre Agreement Contract
A Singapore-law governed preliminary agreement that sets the framework for negotiations and protects parties' interests during deal discussions.
Download
Painting Contract Agreement
A Singapore-compliant contract governing painting services, defining terms between contractor and client.
Download
Independent Contractor And Non Compete
A Singapore-law governed agreement establishing independent contractor terms and non-compete obligations.
Download
Foreign Independent Contractor Agreement
A Singapore law-governed agreement establishing terms between a Singapore-based company and a foreign independent contractor.
Download
Driver Contractor Agreement
A Singapore-compliant legal agreement establishing the relationship between a transportation service provider and an independent driver contractor.
Download
Domestic Subcontract Agreement
A Singapore-governed agreement between main contractor and subcontractor for construction works.
Download
Contractor Service Agreement
A Singapore law-governed agreement establishing terms between contractors and clients for professional services provision.
Download
Contractor Referral Agreement
A Singapore-law governed agreement establishing terms for contractor referrals, including commission structures and referral processes.
Download
Contract For Personal Service
A Singapore-governed agreement establishing terms between an independent contractor and client for provision of professional services.
Download
Contract For Labor Agreement
A legally binding employment agreement for manual labor workers in Singapore, compliant with local labor laws and workplace regulations.
Download
Contract Between Employer And Independent Contractor
A Singapore-law governed agreement establishing terms between a business and independent contractor, defining service scope, payment terms, and relationship parameters.
Download
Consulting Agreement Contract
A Singapore-law governed agreement establishing terms and conditions between a consultant and client for professional services delivery.
Download
Construction Contractor Contract
A Singapore-law governed agreement between principal and contractor for construction works, incorporating local building regulations and industry standards.
Download
Civil Work Contract Agreement
A Singapore-compliant contract governing civil construction works between an employer and contractor, outlining terms, conditions, and obligations.
Download
Subcontractor Hold Harmless Agreement
A Singapore-law governed agreement establishing indemnification obligations between contractor and subcontractor, protecting the principal contractor from liability arising from subcontractor's work.
Download
Salon Contract For Employees
A Singapore-compliant employment contract specifically designed for salon staff, establishing terms of employment and professional standards in the beauty industry.
Download
Part Time Contractor Agreement
A Singapore-law governed agreement establishing terms for part-time contractor services, ensuring clear distinction from employment relationship.
Download
Mining Contractor Agreement
A Singapore-law governed agreement between mining companies and contractors for mining services, incorporating local regulatory requirements.
Download
Home Remodel Contract
A Singapore-governed contract for residential renovation works, establishing terms between homeowner and contractor.
Download
Framework Agreement Contract
A Singapore-law governed agreement establishing terms for ongoing procurement relationships and future contracts.
Download
Construction Warranty Agreement
A legally binding agreement under Singapore law that guarantees construction quality and outlines warranty obligations for defects and repairs.
Download
Construction Service Contract
A legal agreement for construction services in Singapore, governing contractor-client relationships and ensuring compliance with local construction laws.
Download
Contract Agreement Between Two Parties
A customizable legal agreement between two parties under Singapore law, establishing mutual terms and obligations without standardized constraints.
Download
Construction Contract Agreement Form
A standardized construction agreement under Singapore law establishing terms and conditions for building projects.
Download
Binding Agreement Contract
A legally binding contract governed by Singapore law that establishes enforceable terms and conditions between parties.
Download
Agreement Security Guard Contract
A Singapore-law governed contract establishing terms for security guard services, compliant with PSIA regulations.
Download
Agreement For Construction Of House
A Singapore law-governed agreement setting out terms and conditions for house construction, including scope, payments, and responsibilities.
Download
Agreement Between Contractor And Principal Employer
A Singapore-law governed agreement establishing terms between a principal employer and independent contractor, defining services, payments, and obligations.
Download
Independent Contractor Equity Agreement
A Singapore-law governed agreement establishing independent contractor status and equity compensation terms for services provided to a company.
Download
Model Form Contract
A standardized contract template compliant with Singapore law, designed for efficient business transactions.
Download
Company Bond Contract
A Singapore-law governed agreement documenting terms and conditions of corporate bond issuance, establishing rights and obligations between issuer and bondholders.
Download
Construction Owner's Representative Contract
A Singapore law-governed agreement appointing a professional representative to oversee construction projects on behalf of the property owner.
Download
Profit Sharing Agreement Independent Contractor
A Singapore-governed agreement establishing profit-sharing terms between an independent contractor and a business entity.
Download
Loan Officer Independent Contractor Agreement
A Singapore-governed agreement establishing terms between financial institutions and independent contractor loan officers, ensuring regulatory compliance and defining service parameters.
Download
骋别苍颈别鈥檚 Security Promise
Genie is the safest place to draft. Here鈥檚 how we prioritise your privacy and security.
Your documents are private:
We do not train on your data; 骋别苍颈别鈥檚 AI improves independently
All data stored on Genie is private to your organisation
Your documents are protected:
Your documents are protected by ultra-secure 256-bit encryption
We are ISO27001 certified, so your data is secure
Organizational security:
You retain IP ownership of your documents and their information
You have full control over your data and who gets to see it
.png)