The Construction Contract Agreement is a fundamental document for any construction project in Ireland, establishing the legal and commercial framework between the employer and contractor. It is essential for projects ranging from commercial developments to infrastructure works, incorporating mandatory requirements from the Construction Contracts Act 2013 and other relevant Irish legislation. The agreement covers crucial aspects including payment terms, project execution, quality standards, variations, and dispute resolution mechanisms. It should be used whenever engaging a contractor for construction works in Ireland, ensuring compliance with local building regulations, health and safety requirements, and industry standards. The document provides comprehensive protection for all parties while facilitating efficient project delivery within the Irish legal framework.
Your data doesn't train Genie's AI
You keep IP ownership聽of your information
Thank you! Your submission has been received!
Oops! Something went wrong while submitting the form.
OR
Let tiktok成人版's market-leading legal AI identify missing terms, unusual language, compliance issues and more - in just seconds.
1. Parties: Identification and details of the Employer and Contractor
2. Background: Context of the agreement and brief project overview
3. Definitions and Interpretation: Definitions of key terms and interpretation rules
4. Contractor's Obligations: Primary obligations including workmanship, materials, and compliance with laws
5. Employer's Obligations: Primary obligations including site access, permits, and information provision
6. Contract Price and Payment: Payment terms, valuation mechanisms, and payment schedule in compliance with Construction Contracts Act 2013
7. Time and Programme: Completion dates, programme requirements, and extension of time provisions
8. Variations: Procedures for changes to works, valuation of variations, and authority to vary
9. Quality and Defects: Quality standards, inspection rights, and defects correction procedures
10. Health and Safety: Safety obligations, compliance with regulations, and site safety management
11. Insurance and Indemnities: Required insurance coverage and indemnification obligations
12. Termination: Grounds and procedures for contract termination by either party
13. Dispute Resolution: Procedures for dispute resolution including adjudication under the Construction Contracts Act
14. General Provisions: Standard contractual provisions including notices, governing law, and assignment
1. Sectional Completion: Used when the works are to be completed and handed over in sections
2. Nominated Subcontractors: Required when employer-nominated subcontractors are to be used
3. Performance Security: Include when bonds or parent company guarantees are required
4. Price Adjustment: For longer projects where price fluctuation provisions are needed
5. Archaeological Findings: Required for projects in historically sensitive areas
6. Provisional Sums: Include when certain works cannot be precisely defined at contract formation
7. Intellectual Property Rights: When design responsibility or special IP considerations apply
8. Building Information Modelling: Required when BIM is to be used in the project
9. Sustainable Construction Requirements: For projects with specific environmental or sustainability targets
10. Liquidated Damages: When pre-determined damages for delay are to be included
1. Schedule 1 - Contract Documents: List of all documents forming part of the contract
2. Schedule 2 - Works Description: Detailed description of the works including specifications and drawings
3. Schedule 3 - Contract Price Breakdown: Detailed breakdown of the contract price and rates
4. Schedule 4 - Programme Requirements: Detailed programming requirements and key milestone dates
5. Schedule 5 - Site Information: Information about the site including surveys and existing conditions
6. Schedule 6 - Insurance Requirements: Detailed insurance requirements and minimum coverage levels
7. Schedule 7 - Forms of Certificates: Templates for payment, completion, and other certificates
8. Schedule 8 - Key Personnel: Details of key personnel from both parties
9. Schedule 9 - Quality Management Requirements: Quality assurance and control requirements
10. Schedule 10 - Health and Safety Requirements: Detailed health and safety requirements and procedures
11. Appendix A - Form of Performance Security: Template for bonds or guarantees if required
12. Appendix B - Form of Collateral Warranty: Template for collateral warranties if required
Relevant legal definitions
Clauses
Relevant Industries
Commercial Construction
Residential Development
Industrial Construction
Infrastructure Development
Healthcare Construction
Educational Facilities
Retail Development
Hospitality Construction
Sports Facilities
Public Works
Energy Infrastructure
Transportation Infrastructure
Mixed-use Development
Data Center Construction
Relevant Teams
Legal
Construction
Commercial
Procurement
Operations
Finance
Risk Management
Project Management
Technical
Health and Safety
Compliance
Business Development
Contract Administration
Relevant Roles
Construction Director
Project Manager
Commercial Manager
Contracts Manager
Quantity Surveyor
Construction Manager
Site Manager
Legal Counsel
Risk Manager
Procurement Manager
Operations Director
Development Manager
Technical Director
Chief Executive Officer
Finance Director
Project Engineer
Construction Lawyer
Compliance Officer
Health and Safety Manager
Find the exact document you need
Renovation Contract Agreement
An Irish law-governed agreement setting out terms and conditions for property renovation works between a property owner and contractor.
find out more
Electrical Contractor Agreement
An Irish law-governed agreement between an electrical contractor and client for electrical installation, maintenance, or repair services, ensuring compliance with Irish electrical safety standards and regulations.
find out more
Basic Contractor Agreement
An Irish law-governed agreement establishing the terms and conditions between a company and an independent contractor, ensuring clear definition of services and maintaining contractor status.
find out more
Agreement To Rescind Contract
An Irish law-governed agreement that formally terminates an existing contract by mutual consent of the parties.
find out more
Simple Building Contract
An Irish law-governed building contract for small to medium construction projects, establishing rights and obligations between property owners and contractors.
find out more
Construction Company Contract
Irish construction company contract template compliant with local construction laws and regulations, suitable for various construction projects in Ireland.
find out more
Builder Client Contract
An Irish law-governed contract between a builder and client defining construction works, payments, and obligations under Irish construction regulations.
find out more
Labour Contract Form
Standard Irish labour contract outlining employment terms and conditions in compliance with Irish employment law.
find out more
Short Independent Contractor Agreement
An Irish law-governed short-form agreement for engaging independent contractors, balancing legal compliance with practical business needs.
find out more
Contractor Work Contract
An Irish law-governed agreement establishing the terms and conditions between a client and an independent contractor, defining services, payments, and obligations while maintaining contractor independence.
find out more
Indemnity Agreement (Construction)
Irish law construction indemnity agreement establishing risk allocation and protection mechanisms between construction project parties.
find out more
Indemnification Agreement (Construction)
An Irish law-governed agreement establishing indemnification obligations and risk allocation between parties in construction projects.
find out more
Contractor Contract Agreement
An Irish law-governed agreement establishing terms and conditions between a company and an independent contractor, ensuring clear definition of services, payments, and obligations.
find out more
Construction Contract Between Owner And Contractor
An Irish law-governed construction contract between property owner and contractor, compliant with the Construction Contracts Act 2013 and Irish building regulations.
find out more
Non Compete With Independent Contractor
An Irish law-compliant Non-Compete Agreement for independent contractors, protecting business interests while ensuring reasonable restrictions.
find out more
Exclusive Subcontractor Agreement
An Irish law-governed agreement establishing exclusive subcontracting arrangements between a main contractor and subcontractor, defining service delivery and compliance requirements.
find out more
General Contractor Contract Agreement
Irish law-governed construction agreement between an employer and general contractor, compliant with Construction Contracts Act 2013 and Irish building regulations.
find out more
Short Form Contractor Agreement
An Irish law-governed contractor agreement establishing key terms for independent contractor engagements while ensuring compliance with Irish legal requirements.
find out more
Cleaning Contractor Agreement
An Irish law-governed agreement between a client and cleaning contractor establishing terms for professional cleaning services provision.
find out more
House Renovation Contract
An Irish law-governed contract establishing terms and conditions for house renovation works between property owners and contractors.
find out more
Freelance Contractor Agreement
An Irish law-governed agreement establishing the terms and conditions between a company and an independent contractor, defining services, payments, and mutual obligations.
find out more
Subcontractor Service Agreement
An Irish law-governed agreement establishing terms and conditions between a contractor and subcontractor for service provision.
find out more
Sole Trader Contract
An Irish law-governed contract template for engaging sole traders as independent contractors, ensuring proper business relationship structure and regulatory compliance.
find out more
Simple Payment Agreement Contract
An Irish law-governed agreement establishing payment terms, schedules, and obligations between parties, with enforcement mechanisms under Irish commercial law.
find out more
Labour Hire Contract
An Irish law-governed Labour Hire Contract establishing terms between a labour hire agency, worker, and host employer, ensuring compliance with Irish employment legislation.
find out more
Labour Hire Agreement
An Irish law-governed agreement between a labour hire agency and client company for the provision of temporary workers, ensuring compliance with Irish employment legislation.
find out more
Driver Contractor Agreement
An Irish law-governed agreement between a company and an independent driver contractor, establishing terms for transportation services and regulatory compliance.
find out more
Domestic Subcontract Agreement
An Irish law-governed agreement between main contractor and subcontractor for residential construction works, incorporating key requirements of Irish construction legislation.
find out more
Contractor Service Agreement
An Irish law-governed agreement establishing terms and conditions between a company and an independent contractor for the provision of specific services.
find out more
Consulting Agreement Contract
An Irish law-governed agreement establishing the terms and conditions between a client and consultant for professional consulting services.
find out more
Self Employed Consultant Agreement
An Irish law-governed agreement establishing the terms and conditions between a client and a self-employed consultant, defining services, payments, and professional obligations.
find out more
Salon Contract For Employees
An Irish law-governed employment contract for salon staff, outlining terms, conditions, and industry-specific requirements for beauty and wellness professionals.
find out more
Part Time Contractor Agreement
An Irish law-governed agreement establishing terms and conditions for part-time contractor engagement, defining services, payments, and legal obligations.
find out more
Independent Sales Contract
An Irish law-governed agreement establishing terms between a company and independent sales agent, including commission structures and territorial rights.
find out more
Home Remodel Contract
An Irish law-governed contract for home renovation projects, establishing terms between homeowners and contractors while ensuring compliance with Irish construction regulations.
find out more
Framework Agreement Contract
An Irish law-governed agreement establishing terms for ongoing commercial relationships and future call-off contracts.
find out more
Confidentiality Agreement For Independent Contractors
Irish law-compliant confidentiality agreement for independent contractors, incorporating GDPR and local data protection requirements.
find out more
Binding Agreement Contract
An Irish law-governed binding agreement that establishes legal terms and conditions between parties, ensuring enforceability and compliance with Irish legal requirements.
find out more
Electrical Contract Form
An Irish-law electrical contract form for electrical installation and maintenance works, compliant with Irish safety regulations and construction laws.
find out more
Subcontractor Contract Form
An Irish law-governed agreement establishing terms and conditions between a main contractor and subcontractor for the provision of specified works or services.
find out more
骋别苍颈别鈥檚 Security Promise
Genie is the safest place to draft. Here鈥檚 how we prioritise your privacy and security.
Your documents are private:
We do not train on your data; 骋别苍颈别鈥檚 AI improves independently
All data stored on Genie is private to your organisation
Your documents are protected:
Your documents are protected by ultra-secure 256-bit encryption
We are ISO27001 certified, so your data is secure
Organizational security:
You retain IP ownership of your documents and their information
You have full control over your data and who gets to see it
.png)