The Turnkey Contract is a specialized agreement used when an employer requires a complete, ready-to-use facility or project delivered by a single contractor. This document, governed by Maltese law and EU regulations, is particularly suitable for complex projects where the employer wants to minimize their direct involvement in the technical details and coordination of the project. It allocates comprehensive responsibility to the contractor for all aspects including design, procurement, construction, installation, testing, and commissioning. The contract incorporates specific requirements of Maltese construction law, planning regulations, and environmental standards, while ensuring compliance with EU directives. It's commonly used for industrial facilities, infrastructure projects, and commercial developments where single-point responsibility and guaranteed performance are crucial factors.
Turnkey Contract for Malta
Create a bespoke document in minutes, or upload and review your own.
Thank you! Your submission has been received!
Oops! Something went wrong while submitting the form.
Get your first 2 documents free
Your data doesn't train Genie's AI
You keep IP ownership聽of your information
Key Requirements PROMPT example:
Turnkey Contract
"I need a Turnkey Contract for the construction of a pharmaceutical manufacturing facility in Malta, with completion required by June 2025, including specific provisions for GMP compliance and clean room specifications."
Your data doesn't train Genie's AI
You keep IP ownership聽of your information
Thank you! Your submission has been received!
Oops! Something went wrong while submitting the form.
OR
Let tiktok成人版's market-leading legal AI identify missing terms, unusual language, compliance issues and more - in just seconds.
1. Parties: Identification of the Employer and the Contractor, including their registered addresses and company details
2. Background: Context of the project, including brief description of the works and purpose
3. Definitions and Interpretation: Comprehensive definitions of terms used throughout the contract and rules of interpretation
4. Scope of Works: Detailed description of the complete scope, including design, construction, installation, testing, and commissioning
5. Contract Price and Payment Terms: Fixed price, payment schedule, milestones, and payment conditions
6. Time for Completion: Project schedule, key milestones, and completion dates
7. Contractor's Obligations: Comprehensive list of contractor responsibilities including design, procurement, construction, and commissioning
8. Employer's Obligations: Responsibilities of the employer including site access, permits, and approvals
9. Design Responsibility: Allocation of design responsibility and approval processes
10. Quality Assurance and Control: Quality standards, inspection requirements, and testing procedures
11. Testing and Commissioning: Procedures for testing, commissioning, and performance verification
12. Completion and Handover: Requirements for completion, acceptance criteria, and handover procedures
13. Defects Liability: Warranty period, remediation of defects, and maintenance obligations
14. Changes and Variations: Procedures for handling changes and variations to the scope
15. Force Majeure: Definition and consequences of force majeure events
16. Termination: Grounds for termination and consequences
17. Liability and Indemnification: Allocation of risks and responsibilities between parties
18. Insurance: Required insurance coverage and obligations
19. Dispute Resolution: Procedures for resolving disputes including arbitration provisions
20. Governing Law: Specification of Maltese law as governing law and jurisdiction
1. Performance Guarantees: Specific performance guarantees and associated liquidated damages, used when particular performance metrics are crucial
2. Interface Management: Procedures for managing interfaces with other contractors or existing facilities, used in complex projects
3. Environmental Compliance: Specific environmental requirements and obligations, used for projects with significant environmental impact
4. Local Content Requirements: Requirements for local content and employment, used when required by local regulations or project specifics
5. Technology Transfer: Provisions for technology transfer and training, used when required by the employer
6. Intellectual Property Rights: Specific provisions regarding IP rights, used when proprietary technology is involved
7. Step-in Rights: Employer's rights to step in and complete works, used in critical infrastructure projects
8. Confidentiality: Detailed confidentiality obligations, used when sensitive information is involved
1. Schedule 1 - Scope of Works: Detailed technical specifications and scope description
2. Schedule 2 - Site Information: Site details, conditions, and access requirements
3. Schedule 3 - Time Schedule: Detailed project schedule with milestones
4. Schedule 4 - Payment Schedule: Detailed payment terms, milestones, and procedures
5. Schedule 5 - Performance Specifications: Detailed performance requirements and acceptance criteria
6. Schedule 6 - Forms of Guarantees: Templates for various guarantees required under the contract
7. Schedule 7 - Testing and Commissioning Procedures: Detailed procedures for testing and commissioning
8. Schedule 8 - Required Insurances: Details of required insurance coverage
9. Schedule 9 - HSE Requirements: Health, safety, and environmental requirements
10. Schedule 10 - Forms of Certificates: Templates for various certificates including completion certificates
11. Appendix A - Drawings and Technical Documents: Reference drawings and technical documentation
12. Appendix B - Permits and Approvals: List of required permits and responsibilities
Authors
Relevant legal definitions
Clauses
Relevant Industries
Construction and Infrastructure
Energy and Power Generation
Industrial Manufacturing
Commercial Real Estate
Healthcare Facilities
Hospitality and Tourism
Information Technology
Telecommunications
Renewable Energy
Manufacturing Plants
Pharmaceutical Facilities
Waste Management
Water Treatment
Transportation Infrastructure
Relevant Teams
Legal
Project Management
Commercial
Procurement
Engineering
Construction
Finance
Risk and Compliance
Operations
Business Development
Technical Services
Quality Assurance
Contract Administration
Relevant Roles
Project Director
Contract Manager
Legal Counsel
Project Manager
Commercial Manager
Construction Manager
Procurement Manager
Technical Director
Chief Executive Officer
Chief Financial Officer
Risk Manager
Compliance Officer
Operations Director
Business Development Manager
Cost Controller
Design Manager
Quality Assurance Manager
Find the exact document you need
Preliminary Agreement Building Contract
A Maltese law-governed preliminary agreement setting out terms and conditions for a future building contract, including construction specifications and obligations of both parties.
find out more
Contract Work Contract
A Maltese law-governed agreement for engaging independent contractors, establishing terms, conditions, and obligations while ensuring compliance with local employment regulations.
find out more
Contractor And Contractee Agreement
A Maltese law-governed agreement establishing the terms and conditions between a contractor and contractee, defining services, payments, and mutual obligations.
find out more
Terms Of Agreement Contract
A Maltese law-governed Terms of Agreement Contract establishing parties' rights and obligations while ensuring compliance with local and EU regulations.
find out more
House Construction Contract
A Maltese law-governed contract for residential property construction, defining terms between property owner and contractor.
find out more
Contract Between Employer And Contractor
A Maltese law-governed agreement establishing the terms and conditions between an employer and an independent contractor, ensuring legal compliance and protecting both parties' interests.
find out more
Simple Building Contract
A standardized construction agreement under Maltese law for moderate-scale building projects, establishing key terms between employer and contractor.
find out more
Contractor To Contractor Agreement
A Maltese law-governed agreement establishing terms and conditions between two independent contractors or businesses for service provision.
find out more
Lien Contract
A Maltese law-governed agreement establishing a security interest over assets to secure obligations or debt, creating enforceable rights for the creditor under Malta's legal framework.
find out more
Contract With Builder
A Maltese law-governed agreement between property owner and builder for construction works, incorporating local building regulations and industry standards.
find out more
Payment Contract Agreement
A Maltese law-governed agreement establishing payment terms and obligations between parties, ensuring compliance with local and EU financial regulations.
find out more
Basic Work Contract
A standard employment agreement compliant with Maltese law, establishing basic terms and conditions between employer and employee.
find out more
Turnkey Contract
A Maltese law-governed contract for complete project delivery from design through commissioning, placing full responsibility on a single contractor.
find out more
Sub Contractor Agreement
A Maltese law-governed agreement establishing terms and conditions between a contractor and subcontractor for specific services or work.
find out more
Proposal And Contract
A combined proposal and contract document governed by Maltese law that presents business terms and establishes legally binding obligations upon acceptance.
find out more
Marketing Agreement Contract
A Maltese law-governed agreement establishing terms and conditions for marketing services between a service provider and client.
find out more
Joint Contract
A Malta-law governed agreement establishing terms and conditions for multiple parties working together towards a shared objective.
find out more
Contract Forlance Work
Maltese law-compliant freelance work contract template establishing terms for independent contractor relationships while ensuring compliance with local and EU regulations.
find out more
Agreement Between Owner And Electrical Contractor
A Maltese law-governed agreement between property owners and electrical contractors for electrical installation and maintenance services.
find out more
General Contract For Services
A Maltese law-governed service agreement template establishing terms and conditions between service provider and client.
find out more
Landscape Contract
A Maltese law-governed contract for landscaping services, covering design, installation, and maintenance of outdoor spaces.
find out more
Freelance Contractor Agreement
A Malta-law governed agreement establishing terms and conditions between a business and freelance contractor, ensuring compliance with local and EU regulations.
find out more
Contractor Service Agreement
A Maltese law-governed agreement establishing the terms and conditions between a client and an independent contractor for service provision.
find out more
Contract Of Consultancy Services
A Maltese law-governed agreement establishing terms and conditions for professional consultancy services between a service provider and client.
find out more
Consulting Agreement Contract
A Maltese law-governed agreement establishing the terms and conditions between a consultant and client, ensuring compliance with local and EU regulations.
find out more
Contract Between Employer And Independent Contractor
A Maltese law-governed agreement establishing the relationship between a company and independent contractor, defining services, terms, and mutual obligations.
find out more
Contract Between Owner And Contractor
A Maltese law-governed construction agreement between property owner and contractor defining project scope, terms, and mutual obligations.
find out more
Construction Service Contract
A Maltese law-governed agreement setting out terms and conditions for construction services, including scope, payment, and regulatory compliance.
find out more
Binding Agreement Contract
A legally binding agreement contract under Maltese law that establishes formal contractual relationships between parties with enforceable terms and conditions.
find out more
Contract For Service And Contract Of Service
A Maltese law-governed agreement combining employment and service provision arrangements in a single comprehensive framework.
find out more
Independent Worker Contract
A Maltese law-governed Independent Worker Contract establishing terms between a business and contractor, ensuring compliance with local regulations while maintaining contractor independence.
find out more
Building Construction Contract Agreement
A Maltese law-governed agreement establishing terms and conditions between property owners/developers and contractors for construction projects in Malta.
find out more
Employment Contract For Contract Workers
Maltese law-compliant employment contract template for fixed-term contract workers, including all essential terms and statutory requirements.
find out more
Builder Agreement
A Maltese law-governed agreement between a builder and client establishing terms for construction works, including scope, payments, and regulatory compliance.
find out more
Self Employed Barber Contract
A Malta-compliant contract establishing terms and conditions for self-employed barbers operating within salon premises.
find out more
Contract For Building A House
A Maltese law-governed contract establishing terms and conditions for residential house construction, outlining rights and obligations of property owner and builder.
find out more
Basic Building Contract
A Maltese law-governed construction contract establishing terms between property owner and contractor for building works.
find out more
Project Manager Contract Agreement
A Maltese law-governed employment agreement for project management positions, detailing role responsibilities and employment terms in compliance with local regulations.
find out more
Third Party Contractor Agreement
A Maltese law-governed agreement establishing terms and conditions between a company and independent contractor, ensuring legal compliance and clear relationship parameters.
find out more
Property Agreement Contract
A legally binding agreement under Maltese law governing the sale, purchase, or transfer of real property in Malta, detailing all essential terms and conditions of the transaction.
find out more
Business Consulting Contract
A Maltese law-governed agreement establishing terms and conditions for professional consulting services, ensuring compliance with local and EU regulations.
find out more
Independent Consultant Contract
A Maltese law-governed agreement establishing terms and conditions between a client and an independent consultant for professional services delivery.
find out more
Work Agreement Contract
A Maltese law-governed employment agreement establishing terms and conditions of employment in compliance with Malta's employment regulations.
find out more
Personal Agreement Contract
A Maltese law-governed contract establishing terms and conditions for personal arrangements between parties, ensuring compliance with local legal requirements and EU regulations.
find out more
Independent Consultant Agreement
A Maltese law-governed agreement establishing terms and conditions between a client and an independent consultant for professional services provision.
find out more
Cost Plus Contractor Agreement
A Maltese law-governed agreement establishing terms for construction services where the contractor is reimbursed for costs plus an agreed profit margin.
find out more
Settlement Agreement Contract
A Maltese law-governed agreement that formally resolves disputes between parties, detailing settlement terms and mutual releases.
find out more
Contractor Employment Agreement
A Maltese law-governed agreement establishing the terms and conditions for engaging an independent contractor, defining services, payments, and mutual obligations.
find out more
Payment Plan Agreement Contract
A Maltese law-governed agreement that structures debt repayment into defined installments, establishing payment terms and obligations between creditor and debtor.
find out more
Partner Agreement Contract
A Maltese law-governed agreement establishing partnership terms and conditions between business partners, including rights, obligations, and operational framework.
find out more
Fee Agreement Contract
A Maltese law-governed agreement establishing professional service terms and fee arrangements between service providers and clients.
find out more
Home Renovation Contract
A Maltese law-governed contract establishing terms and conditions between homeowner and contractor for residential renovation works.
find out more
Construction Management Contract
A Maltese law-governed agreement between Client and Construction Manager defining the terms and conditions for managing construction projects in Malta.
find out more
House Agreement Contract
A Maltese law-governed agreement establishing terms and conditions for residential property rental, compliant with Malta's Private Residential Leases Act.
find out more
Work Contract
Maltese law-compliant employment contract template establishing terms and conditions between employer and employee, aligned with EIRA requirements.
find out more
Simple Construction Contract
A streamlined construction contract template compliant with Maltese law, suitable for building projects in Malta.
find out more
Simple Contractor Agreement
A Maltese law-governed agreement establishing the terms and conditions between a company and an independent contractor, ensuring clear definition of the business relationship and compliance with local regulations.
find out more
Subcontractor Contract
A Maltese law-governed agreement establishing terms and conditions between a main contractor and subcontractor for specific services or works.
find out more
Service Agreement Contract
A Maltese law-governed agreement establishing terms and conditions between a service provider and client for the provision of professional services.
find out more
Private Contract
A Maltese law-governed Private Contract for formalizing agreements between parties, ensuring compliance with local and EU regulations.
find out more
Home Contract
A Maltese law-governed residential lease agreement establishing terms and conditions for property rental under Malta's Private Residential Leases Act 2020.
find out more
General Contractor Contract
A Maltese law-governed agreement between a property owner and general contractor establishing terms for construction works, including scope, payments, and responsibilities.
find out more
Independent Contractor Contract
A Maltese law-governed agreement establishing the terms and conditions between a company and an independent contractor, defining services, payments, and obligations.
find out more
Independent Contractor Agreement
A Maltese law-governed agreement establishing the terms and conditions between a company and an independent contractor, ensuring legal compliance and clear relationship parameters.
find out more
Indemnity Contract
A Maltese law-governed agreement establishing indemnification obligations between parties, outlining compensation terms for specified losses or liabilities.
find out more
Contractor Contract
Maltese law-governed agreement establishing terms and conditions between a company and independent contractor, ensuring regulatory compliance and clear service parameters.
find out more
Construction Contract Agreement
A Maltese law-governed agreement between client and contractor establishing terms and conditions for construction works, including scope, payments, and compliance requirements.
find out more
Business Agreement Contract
A Maltese law-governed business agreement contract establishing commercial relationships between entities, incorporating key requirements under Maltese and EU legislation.
find out more
骋别苍颈别鈥檚 Security Promise
Genie is the safest place to draft. Here鈥檚 how we prioritise your privacy and security.
Your documents are private:
We do not train on your data; 骋别苍颈别鈥檚 AI improves independently
All data stored on Genie is private to your organisation
Your documents are protected:
Your documents are protected by ultra-secure 256-bit encryption
We are ISO27001 certified, so your data is secure
Organizational security:
You retain IP ownership of your documents and their information
You have full control over your data and who gets to see it
.png)