The Contract For Construction Work is a vital legal document used in Malta for managing construction projects of various scales. It serves as the primary agreement between property owners or developers and construction contractors, establishing clear parameters for construction works while ensuring compliance with Maltese building regulations and construction laws. This document is essential when undertaking any significant construction project in Malta, whether residential, commercial, or industrial. It includes comprehensive details about project scope, timelines, payment structures, quality requirements, and risk allocation, while incorporating specific provisions required under Maltese law such as planning permits, environmental considerations, and workplace safety requirements. The contract is structured to protect all parties' interests while facilitating efficient project execution within the Maltese legal framework.
Contract For Construction Work for Malta
Create a bespoke document in minutes, or upload and review your own.
Thank you! Your submission has been received!
Oops! Something went wrong while submitting the form.
Get your first 2 documents free
Your data doesn't train Genie's AI
You keep IP ownership聽of your information
Key Requirements PROMPT example:
Contract For Construction Work
"I need a Contract For Construction Work for a residential apartment complex in Sliema, Malta, with a project value of 鈧2.5 million, starting March 2025, including specific provisions for phased completion and noise restriction requirements due to the location in a busy residential area."
Your data doesn't train Genie's AI
You keep IP ownership聽of your information
Thank you! Your submission has been received!
Oops! Something went wrong while submitting the form.
OR
Let tiktok成人版's market-leading legal AI identify missing terms, unusual language, compliance issues and more - in just seconds.
1. Parties: Identification and details of the Employer and Contractor, including registration numbers and registered addresses
2. Background: Context of the construction project, including property details and basic project overview
3. Definitions: Definitions of key terms used throughout the contract
4. Scope of Works: Detailed description of the construction works to be performed
5. Contract Price and Payment Terms: Amount payable, payment schedule, retention amounts, and payment procedures
6. Project Timeline: Commencement date, completion date, and key milestone dates
7. Contractor's Obligations: Primary responsibilities of the contractor including quality standards, materials, and workmanship
8. Employer's Obligations: Primary responsibilities of the employer including site access and permits
9. Variations: Procedures for handling changes to the scope of works
10. Health and Safety: Safety requirements and responsibilities in accordance with Maltese regulations
11. Insurance and Indemnities: Required insurance coverage and indemnification provisions
12. Defects Liability: Defects liability period and remediation procedures
13. Termination: Grounds and procedures for contract termination
14. Dispute Resolution: Procedures for resolving disputes including arbitration provisions
15. Governing Law: Confirmation of Maltese law as governing law and jurisdiction
1. Performance Bond: Required for larger projects where additional security is needed
2. Environmental Protection: Specific environmental requirements for environmentally sensitive projects
3. Subcontracting: Terms for engaging and managing subcontractors, if permitted
4. Force Majeure: Provisions for handling unforeseen circumstances and their impact
5. Liquidated Damages: Specific compensation amounts for delay or performance failures
6. Quality Control: Detailed quality management procedures for complex projects
7. Site Security: Special security requirements for sensitive or high-risk locations
8. Materials Storage: Specific requirements for materials storage and handling
9. Warranties: Additional warranties beyond standard defects liability
10. Intellectual Property: IP rights provisions where design elements are involved
1. Schedule 1 - Technical Specifications: Detailed technical requirements and specifications for the works
2. Schedule 2 - Site Plans and Drawings: Architectural and engineering drawings
3. Schedule 3 - Bill of Quantities: Itemized list of materials and works with quantities and rates
4. Schedule 4 - Payment Schedule: Detailed breakdown of payment stages and amounts
5. Schedule 5 - Project Timeline: Detailed project program including milestones
6. Schedule 6 - Quality Standards: Specific quality standards and testing requirements
7. Schedule 7 - Health and Safety Requirements: Detailed health and safety procedures and requirements
8. Schedule 8 - Forms and Certificates: Template forms for variations, completion certificates, etc.
9. Appendix A - Planning Permits: Copies of relevant planning and building permits
10. Appendix B - Insurance Certificates: Copies of required insurance policies
Authors
Relevant legal definitions
Clauses
Relevant Industries
Construction
Real Estate Development
Architecture
Engineering
Property Management
Infrastructure Development
Commercial Property
Residential Property
Industrial Construction
Public Works
Urban Development
Relevant Teams
Legal
Construction
Project Management
Procurement
Health and Safety
Quality Control
Commercial
Finance
Risk Management
Technical Services
Development
Operations
Compliance
Property Management
Relevant Roles
Construction Manager
Project Director
Site Manager
Contract Administrator
Legal Counsel
Quantity Surveyor
Architect
Civil Engineer
Procurement Manager
Health and Safety Officer
Environmental Compliance Officer
Risk Manager
Commercial Director
Technical Director
Development Manager
Construction Supervisor
Project Control Manager
Find the exact document you need
Permanent Full Time Contract
A Maltese law-governed permanent employment contract establishing full-time employment terms and conditions in compliance with local regulations.
find out more
New Employee Contract
Maltese law-compliant employment contract establishing terms and conditions between employer and employee under EIRA regulations.
find out more
Temporary Work Contract
A fixed-term employment agreement under Maltese law establishing a temporary working relationship between employer and employee.
find out more
Unlimited Employment Contract
A Maltese law-governed unlimited employment contract establishing permanent employment terms and conditions in compliance with local employment legislation.
find out more
Labour Hire Contract
A Maltese law-governed agreement establishing terms for temporary employment through a labor hire agency to host companies.
find out more
Continuous Employment New Contract
A Maltese law-governed continuous employment contract establishing permanent employment terms and conditions in compliance with EIRA.
find out more
Work Separation Agreement
A Maltese law-governed agreement that formalizes employment termination, outlining separation terms and ensuring legal compliance for both employer and employee.
find out more
Temporary Contract
Maltese law-compliant temporary employment contract template for fixed-term employment relationships.
find out more
Contract Letter Of Employment
A legally binding employment contract letter compliant with Maltese employment law, establishing the terms and conditions of employment between employer and employee.
find out more
Part Time Fixed Term Contract
Maltese law-compliant Part Time Fixed Term Contract establishing temporary employment with reduced hours and defined duration.
find out more
Minimum Hours Contract
A Maltese law-compliant employment contract guaranteeing minimum working hours while maintaining scheduling flexibility.
find out more
Regular Employee Contract
Standard employment contract template compliant with Maltese employment law and EIRA requirements.
find out more
Domestic Worker Contract
A Maltese law-compliant employment contract for domestic workers, covering essential terms and conditions for household employment.
find out more
Fixed Term Employment Contract
Maltese law-compliant Fixed Term Employment Contract establishing temporary employment relationship with defined duration and terms under EIRA.
find out more
Self Employment Contract
A Maltese law-governed contract establishing a self-employment relationship between a client and an independent contractor, ensuring compliance with local and EU regulations.
find out more
Contract For Construction Work
A Maltese law-governed construction contract establishing terms, conditions, and responsibilities for construction works between an employer and contractor.
find out more
Indefinite Contract
A Maltese law-compliant indefinite employment contract template establishing permanent employment terms and conditions.
find out more
Work Contract Agreement
A Maltese-law governed employment agreement establishing terms and conditions of employment in compliance with Malta's EIRA and EU regulations.
find out more
骋别苍颈别鈥檚 Security Promise
Genie is the safest place to draft. Here鈥檚 how we prioritise your privacy and security.
Your documents are private:
We do not train on your data; 骋别苍颈别鈥檚 AI improves independently
All data stored on Genie is private to your organisation
Your documents are protected:
Your documents are protected by ultra-secure 256-bit encryption
We are ISO27001 certified, so your data is secure
Organizational security:
You retain IP ownership of your documents and their information
You have full control over your data and who gets to see it
.png)